Interwoven Inc. Contracts
Sample Business Contracts
California-Sunnyvale-1195 West Fremont Boulevard Lease [Assignment] - beyond.com and Interwoven Inc.
Lease Forms
- Start a state-specific lease for the rental of commercial property. Specify the term and rent due, as well as whether the landlord or tenant is responsible for property taxes, insurance, and maintenance and repairs.
- When a tenant vacates commercial property before the lease term has expired, it may be able to rent the premises to a third party. The tenant would be the sublessor and the third party would be the sublessee. Besides preparing a sublease, both parties will want to review the provisions for assignment or subletting in the original lease agreement between the landlord and the sublessor.
- Tenants of residential property should prepare a sublease agreement if they are seeking to sublease a room or the entire apartment or house to a third party. All parties should review the original lease agreement to see if there are any restrictions on subletting or assigning the premises.
- Triple net leases are a type of commercial leases where the tenant has to pay for property taxes, insurance, utilities, and maintenance, in addition to the monthly rent.
- When renting an office space, tenants should understand the amount of the rent and duration of the lease. Other important terms include whether the space can be subleased, which parties are responsible for maintenance, and whether any furniture and furnishings will be provided.
ASSIGNMENT OF LEASE
-------------------
Recitals
--------
Section 1. Effective Date of Assignment
Section 2. Assignment
Section 3. Assumption of Lease Obligations/Indemnity
Section 4. Covenants
Section 5. Sublease Cash Security Deposit/Letter of Credit
Section 6. Brokers
Section 7. Condition of Premises
Section 8. Successors and Assigns
Section 9. Governing Law
Section 10. Attorneys' Fees
Section 11. Counterparts
Exhibit A. Master Lease
Exhibit B. Sublease
This Assignment of Lease ("Assignment") is made to be effective as of the
Effective Date (as defined below) between beyond.com, a Delaware corporation
("Assignor"), and Interwoven, Inc., a California corporation ("Assignee").
Recitals
--------
A. SUNNYVALE PARTNERS LIMITED PARTNERSHIP, an Illinois limited
partnership, as landlord ("Landlord"), and FIRST DATA MERCHANT SERVICES
CORPORATION as tenant ("Tenant"), entered into a lease, made as of March 18,
1997 ("Master Lease"), with respect to premises described in the Master Lease
and commonly known as 1195 West Fremont Boulevard, Sunnyvale, California
("Master Premises").
B. A copy of the Master Lease (with certain confidential economic details
deleted) is attached to this Assignment as Exhibit A.
C. Tenant, as sublessor ("Sublessor"), subleased a portion of the
Premises (the "Subleased Premises") to Software.Net Corporation (whose name was
changed to beyond.com), as sublessee, by means of a an undated Sublease, (the
"Sublease").
D. A copy of the Sublease is attached to this Assignment as Exhibit B.
E. Interwoven occupies the balance of the Master Premises pursuant to a
Sub-Sublease with Tenant. Interwoven is familiar with the Landlord, Sublessor,
the building in which the Subleased Premises are located and the operation of
the Master Premises.
<PAGE>
F. beyond.com desires to assign to Interwoven, and Interwoven desires to
receive an assignment from beyond.com, all of the Subleased Premises which is
identified in the Sublease ("Subleased Premises"). From and after the Effective
Date, Interwoven shall be responsible for and shall assume all obligations of
beyond.com under the Sublease accruing on or after the Effective Date.
G. The assignment of the Subleased Premises is conditioned upon Landlord
and Sublessor both consenting to the terms and conditions of this Assignment.
NOW, THEREFORE, in consideration of the mutual promises and covenants
contained herein, the parties hereto agree as follows:
Section 1. Effective Date of Assignment
----------------------------------------
This Assignment shall become effective upon the first day ("Effective
Date") on which each of the following have occurred: (i) this Assignment has
been executed by Assignor and by Assignee, and each has received a copy executed
by the other party; (ii) Assignee has delivered to Assignor $297,454.50 in cash
in the form of a certified bank check as described in clause 5(a); (iii)
Assignee's letter of credit in the amount of $297,454.50 as called for in
Section 5 has been issued with Sublessor as beneficiary; (iv) Sublessor has
released Assignor's letter of credit, as described in clause 5(b); (v) Sublessor
and Master Landlord have consented in writing to this Assignment with no
additions, deletions or amendments; (vi) Assignee has executed the Bill of Sale
for certain personal property and delivered to Assignor the sum of $288,000, by
certified bank check, pursuant to the Bill of Sale; (vii) Assignee has delivered
to Sublessor insurance certificates evidencing all insurance required under the
Sublease, in form acceptable to Sublessor, and (viii) Assignor has tendered
possession of the Subleased Premises to Assignee. If all of the above have not
occurred on or before November 22, 1999, this Assignment shall automatically
terminate and be of no further force and effect. Assignor and Assignee shall
execute a certificate certifying the date that all conditions have been met.
Section 2. Assignment
----------------------
As of the Effective Date, Assignor hereby assigns and transfers to Assignee
all of Assignor's right, title, and interest in the Sublease and Assignee hereby
accepts from Assignor all of Assignor's right, title, and interest, subject to
the terms and conditions set forth in this Assignment. As of the Effective Date.
Assignor releases all right, title and interest it has or may have with respect
to the cash security deposit provided for in Section 30 of the Sublease.
Section 3. Assumption of Lease Obligations/Indemnity
-----------------------------------------------------
Effective as of the Effective Date, Assignee assumes and agrees to perform
and fulfill all the terms, covenants, conditions, and obligations accruing on or
after the Effective Date and required to be performed and fulfilled by Assignor
as sublessee under the Sublease, including the making of all payments due to
Sublessor under the Sublease or payable by Assignor as Sublessee under the
Sublease, all as they become due and payable. Assignee shall indemnify, defend
and hold harmless Assignor from and against any and all claims, costs,
2
<PAGE>
expenses, liabilities, obligations and damages of any nature whatsoever arising
from Assignee's default under the Sublease (collectively "Claims"). Without
limiting the foregoing, if any Claim is made against Assignor, Assignee shall
defend Assignor with counsel reasonably acceptable to Assignor.
Section 4. Covenants
---------------------
(a) Assignor covenants as follows: (i) that the copy of the Sublease
attached as Exhibit B is a true and accurate copy of the Sublease as of the
Effective Date and that there exists no other agreement affecting Assignor's
tenancy under the Sublease; (ii) the copy of the Master Lease attached as
Exhibit A, to the best of Assignor's knowledge, is a true and accurate copy of
the Master Lease as of the Effective Date; and (iii) the Sublease is in full
effect and, to the best of Assignor's knowledge, no defaults exist under the
Sublease, nor any acts or events which, with the passage of time or the giving
of notice or both, could become defaults.
(b) Assignee covenants as follows: (i) that it has read the Master Lease
attached hereto and the Sublease; and (ii) that as of the Effective Date it
shall have made such investigations of the Subleased Premises as it deems
necessary to determine that the Subleased Premises are acceptable to it.
Section 5. Sublease Cash Security Deposit/Letter of Credit
-----------------------------------------------------------
(a) On or before the Effective Date, Assignee shall pay Assignor
$297,454.50 in cash in the form of a certified bank check in exchange for
Assignor's assignment to Assignee of all of Assignor's right, title and interest
in the $297,454.50 cash security deposit provided for in Section 30 of the
Sublease ("Sublease Security Deposit").
(b) On or before the Effective Date, Assignee shall deliver to Sublessor
$297,454.50 in the form of an irrevocable letter of credit (the "Letter of
Credit Security Deposit") issued by a bank acceptable to Sublessor and in form
and substance acceptable to Sublessor (the "Letter of Credit") and otherwise in
full compliance with Section 30 of the Sublease. Concurrently with the delivery
to Sublessor of Assignee's Letter of Credit Security Deposit, Sublessor shall
cause Assignor's letter of credit (which Sublessor currently holds as security
under Section 30 of the Sublease) to be released provided, however, no such
release shall occur unless and until Sublessor has received and approved
Assignee's Letter of Credit Security Deposit. The release by Sublessor of
beyond.com's letter of credit on or before November 22, 1999 shall be a
condition to the effectiveness of Assignor's assignment hereunder. If Assignor's
letter of credit is not released on or before such date, on twenty-four hours
written notice Assignor may rescind this Assignment at any time until its letter
of credit is released.
Section 6. Brokers
-------------------
Assignor and Assignee acknowledge that no real estate broker brought about
this assignment transaction. Each party hereby agrees to indemnify the other
party against claims of any person claiming by, through or under the first party
in connection with this assignment transaction.
3
<PAGE>
Section 7. Condition of Premises
---------------------------------
Assignor makes no representations or warranties with regard to the
conditions of the Subleased Premises. Assignee is in occupancy of the building
in which the Subleased Premises are located and is familiar with the building
systems that service the building and with the custom and practice of Sublessor.
Assignee may investigate the Subleased Premises and all parts thereof prior to
signing this Assignment. To the best of beyond.com's knowledge, without
investigation, beyond.com has received no notice that the Subleased Premises are
in violation of any ordinance, rule, code or regulation of any governmental
agency.
Section 8. Successors and Assigns
----------------------------------
This Assignment shall be binding on and inure to the benefit of the parties
to it, their successors-in-interest, and assigns.
Section 9. Governing Law
-------------------------
This Assignment shall be governed by and construed in accordance with
California law.
Section 10. Attorneys' Fees
----------------------------
If either party commences an action against the other in connection with
this Assignment, the Sublease, for indemnity or any matter related thereto, the
prevailing party will be entitled to recover costs of suit and reasonable
attorneys' fees.
Section 11. Counterparts
-------------------------
This Assignment may be executed in counterparts, each of which shall be
deemed an original, but all of which together shall constitute one and the same
instrument.
The parties have executed this Assignment as of the date first above
written.
Assignor: beyond.com, a Delaware corporation
By: /s/ Garry Stuib
-------------------------
Title: Director of HR
-------------------------
Assignee: Interwoven, Inc., a Delaware corporation
By: David M. Allen
-------------------------
Title: V.P. & CFO
-------------------------
4
<PAGE>
Consent of Master Landlord
--------------------------
First Data Merchant Services Corporation ("First Data"), Tenant under the
Master Lease and Sublandlord under the Sublease and Sunnyvale Partners Limited
Partnership ("Sunnyvale Partners"), Landlord under the Master Lease, hereby
consent to this Assignment of the Sublease to Assignee and Sunnyvale Partners
confirms that the consent given hereby satisfies the requirements for giving
consent as set forth in the Master Lease regarding this Assignment and First
Data confirms that the consent given hereby satisfies the requirements for
giving consent as set forth in the Sublease regarding this Assignment. However,
Assignor and Assignee remain otherwise subject to all terms and conditions of
Section 18 of the Sublease as set forth in the Master Lease. By so consenting to
the Assignment of the Sublease, Sunnyvale Partners and First Data do not hereby
consent to become a party to the Assignment. If the Master Lease is terminated
prior to the termination of the Sublease, the Sublease shall terminate
simultaneously therewith and Assignee's rights to possess to any portion of the
Subleased Premises arise solely from the provisions of the Sublease and neither
the Sublease nor this consent shall be deemed as granting Assignee any greater
tenancy rights than Subtenant under the Sublease. Nothing in this Consent or the
Assignment shall be deemed to be either (i) a modification of or an amendment to
the Sublease or Master Lease; or (ii) a release of beyond.com from its
obligations under the Sublease or a modification of any of beyond.com's
obligations under the Sublease. First Data hereby consents to the right of
beyond.com to cure any defaults by Assignee under the Sublease provided such
defaults are cured within the time periods set forth in the Sublease.
Notwithstanding any provision to the contrary in this Consent, nothing contained
herein shall operate as a consent to or approval or ratification by First Data
or Sunnyvale Partners of any of the provisions of the Assignment or as a
representation or warranty by First Data or Sunnyvale Partners, and neither
First Data nor Sunnyvale Partners shall be bound or estopped in any way by the
provisions of the Assignment. In addition, nothing herein shall be construed to
waive any future or present breach or default on the part of beyond.com under
the Sublease.
Sunnyvale Partners
Sunnyvale Partners Limited Partnership,
a California limited partnership
By: /s/ James Small
--------------------------------
Title: General Partner
First Data Merchant Services Corporation,
a Florida corporation
By: /s/ David Schlapbach
--------------------------------
Title:
--------------------------------
<PAGE>
EXHIBIT A
BUILD-TO-SUIT LEASE AGREEMENT
-----------------------------
Landlord: SUNNYVALE PARTNERS LIMITED PARTNERSHIP
Tenant: FIRST DATA MERCHANT SERVICES CORPORATION
March 18, 1997
<PAGE>
EXHIBIT A
TABLE OF CONTENTS
1. Description........................................................... 1
2. Term and Occupancy.................................................... 1
3. Rent.................................................................. 2
4. Construction.......................................................... 3
5. Use................................................................... 7
6. Condition of demised Premises......................................... 8
7. Maintenance and Repairs............................................... 8
8. Alterations........................................................... 9
9. Signs................................................................. 11
10. Services.............................................................. 11
11. Compliance with Law................................................... 12
12. Landlord's Title, Authority, and Quiet Enjoyment; Tenant's Authority.. 13
13. Subordination......................................................... 13
14. Assignment and Sublease............................................... 14
15. Lease Extension....................................................... 15
16. Impositions........................................................... 16
17. Insurance............................................................. 18
18. Destruction and Restoration........................................... 20
19. Condemnation.......................................................... 22
20. Default by Tenant..................................................... 26
21. Landlord's Remedies................................................... 27
22. Default by Landlord................................................... 28
23. Tenant's Remedies..................................................... 28
i
<PAGE>
EXHIBIT A
24. Delivery of Executed Lease............................................ 29
25. Termination........................................................... 29
26. Notices............................................................... 29
27. Brokerage............................................................. 30
28. Estoppel.............................................................. 30
29. Hazardous Substances.................................................. 30
30. Holdover.............................................................. 32
31. Surrender............................................................. 32
32. Liens................................................................. 33
33. Interest; Late Charge................................................. 34
34. Inspections........................................................... 34
35. Transfer of Landlord's Interest....................................... 34
36. Indemnity............................................................. 35
37. Modifications of Lease................................................ 35
38. Memorandum of Lease................................................... 36
39. Paragraph Captions.................................................... 36
40 Entire Agreement...................................................... 36
41. Choice of Law and Interpretation...................................... 36
42. Prevailing Party...................................................... 36
43. Exhibits.............................................................. 36
44. Guarantee............................................................. 37
45. Independent Covenants................................................. 37
46. Entry by Landlord..................................................... 37
47. [Deleted by intent of parties.]....................................... 37
48. Survival of Obligations............................................... 37
ii
<PAGE>
49. Lease Subject to Landlord's Acquisition of Demised Premises........... 38
50. Americans With Disabilities Act....................................... 38
51. Reports by Tenant..................................................... 39
52. Option to Purchase.................................................... 39
53. No Third Party Beneficiaries.......................................... 41
54. Counterparts.......................................................... 41
55. Consents and Approvals................................................ 41
56. Limitation on Damages................................................. 41
57. Tenant's Property..................................................... 41
Exhibit A - Legal Description
Exhibit B - Site Plan
Exhibit C - Plans
Exhibit C-1 - Construction Schedule
Exhibit D - Schedule of Rents
Exhibit E - Lease Term Agreement
Exhibit F - Memorandum of Lease
Exhibit G - Landlord's Development Costs
Exhibit H - Permitted Exceptions
Exhibit I - Escrow Agreement
iii
<PAGE>
THIS BUILD-TO-SUIT LEASE AGREEMENT (this "Lease") is made as of the 18th day of
March, 1997 (the "date hereof") between SUNNYVALE PARTNERS LIMITED PARTNERSHIP,
an Illinois limited partnership, having its principal office at c/o Ridge
Sunnyvale, Inc., c/o Ridge Capital Corporation, 257 East Main Street,
Barrington, Illinois 60010 (hereinafter referred to as "Landlord"), and FIRST
DATA MERCHANT SERVICES CORPORATION, having its principal office at 5660 New
Northside Drive, Suite 1400, Atlanta, Georgia 30328 (hereinafter referred to as
"Tenant").
W I T N E S S E T H:
- - - - - - - - - -
Landlord, for and in consideration of the rents, covenants and agreements
hereinafter set forth on the part of Tenant to be paid, kept, observed and
performed does hereby lease unto Tenant, and Tenant does hereby take subject to
the conditions herein expressed, all that parcel of land situated in the City of
Sunnyvale, County of Santa Clara, State of California and legally described on
Exhibit A attached hereto and made a part hereof (the "Land"), together with all
improvements located and to be constructed thereon by Landlord, which are
hereinafter called "Landlord's Improvements." Landlord's Improvements and all
improvements, machinery, building equipment, fixtures and other property of
Landlord, real, personal or mixed (except Tenant's trade fixtures and any other
property of Tenant), installed or located thereon, together with all additions,
alterations and replacements thereof are collectively referred to herein as the
"Improvements." The Land and the Improvements are sometimes hereinafter
collectively referred to as the "Demised Premises". The structure located upon
and being a part of the Demised Premises which is constructed to be used as a
two story office building containing approximately 80,000 "useable square feet"
(as defined in Paragraph 4 below) is hereinafter referred to as the "Building".
1. Description. Landlord will cause Landlord's Improvements (including
the Building and other site improvements depicted on the Site Plan attached
hereto and made a part hereof as Exhibit B) to be constructed in substantial
accordance with the plans and specifications enumerate on Exhibit C (the
"Plans"). Landlord agrees that Landlord shall not make any modifications or
changes to the Plans without Tenant's prior written consent. Landlord further
agrees to make any changes to the Plans requested by Tenant in writing and if
the change requested by Tenant increases or decreases the cost of the Demised
Premises, the Base Rent provided for herein shall be adjusted in accordance with
the provisions of the formula provided on Exhibit D.
2. Terms and Occupancy. A. The term of this Lease shall commence on the
Construction Completion Date, as provided in Paragraph 4 below (hereinafter
referred to as the "Commencement Date"), and shall end on the date which is the
last day of the month that includes the twelfth (12th) anniversary of the
Commencement Date (hereinafter referred to as the "Expiration Date"), unless the
term be extended or earlier terminated as provided herein.
Landlord shall notify Tenant of the anticipated Construction Completion
Date. Landlord agrees to notify Tenant promptly from time to time of any changes
in the anticipated Construction Completion Date. Tenant shall have the right to
enter the Demised Premises during the approximately ninety (90) day period
preceding the Construction Completion Date for the purpose of installing its
equipment and Tenant does hereby agree to assume all risk of loss or
<PAGE>
damage to such equipment, and to indemnify, defend, and hold harmless Landlord
from and against any loss or damage to such equipment and all liability, loss or
damage arising from any injury to the property of Landlord, or its contractors,
subcontractors or materialmen, and any death or personal injury to any person or
persons arising out of such installation. Landlord agrees to cooperate with
Tenant so that Tenant's contractors and tradespeople will be permitted to
reasonably perform their work without material interference. Tenant agrees to
cooperate with Landlord so that Landlord's contractors and tradespeople will be
permitted to reasonably perform their work without material interference.
B. Notwithstanding anything else in this Lease to the contrary, Tenant
shall have the right to terminate this Lease as of the end of the eighth (8th)
Lease Year (the "Early Termination Date") provided that Tenant shall (a) notify
Landlord in writing of its election to terminate at least one (1) year prior to
the Early Termination Date, and (b) pay to the Landlord, concurrently with the
notification to Landlord hereunder, a termination fee by certified or cashier's
check or wire transfer of available funds ("Termination Amount") equal to the
discounted present value (using Landlord's financing interest rate) amount
needed to reduce the remaining unamortized principal balance due on the
indebtedness originally incurred by Landlord to finance the Landlord's
Development Costs (as defined in Paragraph 19F) to [deleted text]. If Tenant
gives such notice as required hereunder and pays the Termination Amount
concurrently therewith, this Lease shall be deemed terminated as to all rights
or obligations hereunder (except such rights and obligations as Landlord and
Tenant would otherwise have upon normal expiration of the term of this Lease).
Any such notice hereunder, not accompanied by the Termination Amount as provided
hereinabove, shall be deemed invalid and of no force or effect. Upon Landlord's
closing on the permanent loan for the financing of the Landlord's Development
Costs, Landlord shall provide to Tenant a copy of the twenty (20) year permanent
loan amortization (the "Loan Amortization"), which shall include the principal
amount that will be due at the end of the eighth (8th) Lease Year.
Tenant shall have the right to pay the Termination Amount to any mortgagee
of the Demised Premises or other person with a lien on the Demised Premises or
the rents derived therefrom, but Tenant shall have no such obligation to do so
unless such obligation is specifically set forth in a non-disturbance or other
agreement between Tenant and such mortgagee or other lienholder. Notwithstanding
the foregoing, Tenant acknowledges and agrees that any payment to any such
mortgagee or other lienholder shall only be effectuated by a two-party or two-
payee certified or cashier's check, made payable to both Landlord and any such
mortgagee or other lienholder.
3. Rent. The annual base rental ("Base Rent") shall be calculated in
accordance with the provisions set forth on the Schedule of Rents attached
hereto and made a part hereof as Exhibit D. Base Rent shall be paid monthly, in
advance, in equal installments, without offset or deduction by wire transfer in
accordance with separate instruction given by Landlord to Tenant, on the
Commencement Date and on the first day of each month thereafter during the term
hereof; provided however, that if the term of this Lease shall commence on a
date other than the first day of a calendar month or end on a date other than
the last day of a calendar month (i) the first and last month's Base Rent shall
be prorated based upon the ratio that the number of days in the term within such
month bears to the total number of days in such month, and (ii) Base Rent
reserved for the calendar month of any scheduled rent escalation shall be
equitably adjusted upon due
2
<PAGE>
consideration of the number of days in such month falling within the preceding
Lease Year (as herein defined) and the number of days in such month falling
within the current Lease Year. For purposes of this Lease, the term "Lease Year"
shall mean the 12-month period commencing on the Commencement Date and each 12-
month period thereafter during the term of this Lease (and any renewal or
extension thereof), provided that, if the Commencement Date is not the first day
of a calendar month, the first "Lease Year" shall be the period commencing on
the Commencement Date and ending on the last day of the twelfth (12th) full
calendar month following the Commencement Date and all Base Rent payable for the
month in which the Commencement Date occurs shall be paid on the first day of
the following calendar month. Notwithstanding the foregoing, on or prior to the
date of closing under the Sale Agreement (as defined herein), Tenant shall also
deposit into escrow with First American Title Guaranty Company the sum of Two
Million Dollars ($2,000,000.00) to cover a portion of the Landlord's Development
Costs which shall be disbursed in accordance with the Escrow Agreement attached
hereto as Exhibit I.
4. Construction.
A. Landlord agrees, at Landlord's sole cost and expense, to cause
construction of Landlord's Improvements in accordance with the following
schedule:
(a) Landlord shall use all reasonable efforts to commence the Site
Preparation Phase (as defined in that certain Real Estate Purchase and Sale
Agreement and Joint Escrow Instructions dated March 18, 1997 (the "Sale
Agreement") between Regis Homes of Northern California, Inc. and Landlord)
as soon as possible following the date Landlord acquires the Land and in
any event on or before the date four (4) business days following the date
Landlord acquires the Land (the "Estimated Construction Commencement
Date"), in accordance with the Plans and in accordance with the
construction schedule attached hereto as Exhibit C-1 (the "Construction
Schedule") and shall diligently pursue construction in an effort to
complete Landlord's Improvements on or before the Estimated Construction
Completion Date (as herein defined); provided, however, if delay is caused
or contributed to by act or neglect of Tenant, or those acting for or under
Tenant including, without limitation, changes ordered by Tenant, or delays
caused by labor disputes, casualties, acts of God or the public enemy,
governmental embargo restrictions, shortages of fuel, labor, or building
materials, action or non-action of public utilities, or of local, State or
Federal governments affecting the work, or other similar causes beyond the
Landlord's reasonable control, then the time of commencement of said
construction shall be extended for the additional time caused by such delay
(such delays are each hereinafter referred to as an "excused delay"). The
date on which Landlord actually commences construction of Landlord's
Improvements shall be referred to as the "Construction Commencement Date."
(b) Landlord shall use all reasonable efforts to substantially
complete construction of Landlord's Improvements as soon as possible
following the Construction Completion Date in accordance with the
Construction Schedule attached hereto as Exhibit C-1, as may be extended by
excused delays (the
3
<PAGE>
"Estimated Construction Completion Date"). The date on which Landlord
substantially completes construction of Landlord's Improvements (except for
work to be performed by Tenant) shall be referred to as the "Construction
Completion Date." Landlord acknowledges that Tenant will suffer significant
damages if Landlord fails to deliver the Demised Premises on or before the
Estimated Construction Completion Date and that time is of the essence with
respect to Landlord's completion of the Landlord's Improvements as required
herein. If Landlord fails to cause the Landlord's Improvements to be
substantially completed on or before the Estimated Construction Completion
Date, as said date may be extended from time to time due to excused delays,
Landlord shall be obligated to pay to Tenant the following sums for each
day after the Estimated Construction Completion Date until the Construction
Completion Date up to the maximum of sixty-five (65) days of delay and
thereafter, Landlord shall be liable for Tenant's actual damages for the
delay (which shall include Tenant's actual costs incurred in connection
with holding over at its present location and/or renting reasonably
acceptable substitute space): (a) for the first thirty (30) days of delay,
the sum of One Thousand Dollars ($1,000.00) per day for each calendar day
of delay; (b) for the thirty-first (31st) day through the sixtieth (60th)
day of delay, the sum of Two Thousand Five Hundred Dollars ($2,500.00) per
day for each calendar day of delay; and (c) for the sixty-first (61st) day
through the sixty-fifth (65th) day of delay, the sum of Seven Thousand Five
Hundred Dollars ($7,500.00) per day for each calendar day of delay.
Notwithstanding the foregoing, in no event shall Landlord be liable to
Tenant for any punitive, special, incidental, indirect or consequential
damages of any kind whatsoever, each of which is hereby excluded by
agreement of the parties regardless of whether or not any party has been
advised of the possibility of such damages. Landlord shall pay the sums
calculated above (other than actual damages accrued after the 95th day of
delay) within thirty (30) days after the Commencement Date. In connection
with the foregoing, Landlord agrees to deposit into escrow for the benefit
of Tenant all damages received from Regis Contractors of Northern
California, L.P. pursuant to Section 1.7 of that certain Construction
Management Agreement dated March 18, 1997. Tenant agrees to deliver to
Landlord an accounting of Tenant's actual damages upon request.
B. Tenant or its architect will from time to time upon written request of
Landlord or Landlord's construction lender certify that the construction of
Landlord's Improvements has been completed to that point to the reasonable
satisfaction of Tenant. Notwithstanding the foregoing, nothing contained herein
shall be deemed to abrogate, waive or compromise any of Tenant's rights
hereunder with respect to the construction and completion of Landlord's
Improvements.
C. In the event this Lease has not been terminated pursuant to Paragraph
49 of the Lease, Landlord and Tenant promptly shall execute a document
substantially in the form attached hereto as Exhibit E and made a part hereof,
to establish the Commencement Date and the Expiration Date.
4
<PAGE>
D. The following phrases have the meanings set forth below:
(a) The phrase "commence[d][s] construction of Landlord's
Improvements" as used herein means issuance of all necessary permits needed
to commence construction, a building permit, execution of a construction
contract or contracts for the completion of Landlord's Improvements in
accordance with the Plans, execution of this Lease, and excavation work has
commenced.
(b) The phrase "substantial[ly] complete[ed] [ion] [of] construction
of Landlord's Improvements as used in this Lease shall mean the
municipality having jurisdiction thereof issues a certificate of occupancy
permitting Tenant to occupy Landlord's Improvements or takes such other
action as may be customary to permit occupancy or use thereof for the
purposes provided herein and Landlord's Improvements are otherwise ready
for beneficial use and occupancy by Tenant subject to completion of any
punchlist items (as defined herein) by Landlord and Landlord's architect
certified to Tenant in writing that Landlord's Improvements have been
constructed and completed in a good and workmanlike manner in substantial
accordance with the Plans and that to the best of its knowledge the Plans
comply with applicable laws, including without limitation all building
codes, zoning ordinances and regulations and the Act (as defined herein)
and Landlord's Improvements are otherwise ready for beneficial use and
occupancy by Tenant subject to completion of any punchlist items by
Landlord; provided, however, the issuance of a certificate of occupancy or
such other action as may be customary to permit occupancy or use thereof
and the issuance of the architect's certificate shall not be a condition to
payment of rent or commencement of the term if failure to secure such
certificate of occupancy or action or architect's certificate is caused by
the act or neglect of Tenant or if matters required for issuance are the
responsibility of Tenant.
(c) The phrase "usable square feet" means the square feet contained
within the inside of the exterior walls of the Building.
E. Within fifteen (15) days after the Construction Completion Date,
Tenant, Landlord and Landlord's Architect shall prepare and execute a punchlist
(the "punchlist") of incomplete and incorrect items which shall include details
of construction and mechanical and electrical adjustments which are minor in
character and do not materially interfere with Tenant's use or enjoyment of the
Demised Premises in accordance with the provisions of this Lease, and may also
include landscaping and other items which do not materially affect Tenant's use
of the Demised Premises but which cannot be immediately completed because of
weather, or any items listed on the Plans or the Construction Schedule as items
to be completed after substantial completion of the Landlord's Improvements, if
any (such items are sometimes hereinafter referred to as "punchlist items").
Landlord shall use all reasonable efforts to complete the punchlist items as
soon as possible after its receipt of the punchlist, and to minimize disruption
of Tenant's business and other inconveniences to Tenant, subject to excused
delays. If Landlord fails to complete the punchlist items within ninety (90)
days after the receipt by Landlord of the completed punchlist by Tenant, subject
to excused delays, then Tenant shall have the right, but not the obligation, to
complete the punchlist items and the Landlord shall reimburse Tenant for its
5
<PAGE>
reasonable out-of-pocket expenditures in connection therewith upon presentation
of invoices in sufficient detail and upon waivers covering performance of the
work. Nothing herein contained shall be deemed or construed to permit Tenant to
offset against Base Rent or other charges payable by Tenant hereunder. Landlord
shall deliver to Tenant "as built" working drawings of the Landlord's
Improvements within sixty (60) days after completion of the punchlist items.
Landlord shall maintain a retainage of a minimum of ten percent (10%) of
the cost of the so-called tenant improvement portion of the Landlord
Improvements (the "TI Work") or, based on an estimated approximate cost of for
the TI Work. The aforementioned retainage shall not be released until the
punchlist items for TI Work have been completed to Tenant's reasonable
satisfaction.
F. Landlord shall at its own expense correct or repair any parts of
Landlord's Improvements that fail to conform with the requirements of the Plans
during the period of construction of Landlord's Improvements (unless Tenant is
willing to accept such non-conforming work and so notifies Landlord thereof in
writing). Landlord shall correct any defects in the construction of Landlord's
Improvements not caused by Tenant which appear within a period of one (1) year
from the Construction Completion Date, but not otherwise. Landlord shall obtain
for the joint benefit of Landlord and Tenant, a joint, non-exclusive assignment
of all contractor, subcontractor, equipment, material and manufacturers'
warranties relating to the Landlord's Improvements which shall contain a minimum
of a one (1) year warranty period commencing with the contractors' or
subcontractors' completion of the work included in Landlord's Improvements (the
"Warranties"). Furthermore, on the Construction Completion Date, Landlord shall
assign to Tenant the non-exclusive right to enforce any and all Warranties and
Landlord agrees to reasonably cooperate with Tenant's pursuit of any and all
claims under the Warranties.
G. Tenant shall have the right to request that changes be made to the
Plans. Within ten (10) days after Tenant's requests, Landlord shall provide an
estimate of the amount that the change will increase or decrease the cost of
completing the Landlord's Improvements and the time adjustment to the
Construction Schedule, if any. If Tenant approves the change following receipt
of the estimates, Landlord shall submit a change order to its contractors to
implement the change requested by Tenant. The estimated increase or decrease in
the time required to complete the Landlord's Improvements resulting from
Tenant's change shall be reflected as an adjustment to the Construction Schedule
and shall be deemed an "excused delay" and any net increase or decrease in
Landlord's construction costs due to Tenant's change order, shall be borne by or
credited to Tenant, as the case may be, by means of an adjustment to the
Schedule of Rents in accordance with the formula established on Exhibit D.
H. If due to change orders initiated by Tenant, Landlord's Development
Costs exceed the amount of [deleted text] then concurrent with any such change
order, Tenant agrees to deposit into the escrow created by the Escrow Agreement
(as defined in Paragraph 3 hereof) the total amount of any such increase in
Landlord's Development Costs in excess of [deleted text]. Notwithstanding the
foregoing, upon the closing of the permanent financing for the Demised Premises
occurring on or after the Commencement Date, Landlord shall reimburse Tenant for
all such increased costs and the Base Rent shall be adjusted in accordance with
the formula
6
<PAGE>
established on Exhibit D; provided, however, Base Rent shall not be adjusted
until such time as Tenant is reimbursed hereunder.
5. Use.
A. The Demised Premises shall be used and occupied for general office
purposes and for any other purpose which does not violate any applicable law,
rule, ordinance or regulation of any applicable government authority having
jurisdiction ("Tenant's Use"). Landlord represents that, to its actual
knowledge, the Demised Premises are currently zoned "O," Administrative-
Professional District and R1.7/PD, low medium density residential district under
the zoning ordinance of the City of Sunnyvale, California, which zoning
classification, to Landlord's actual knowledge, will not restrict or limit
Tenant's Use; provided, however, Landlord makes no representation as to whether
a special use permit, zoning variance or comparable relief from the local zoning
ordinance is required to conduct Tenant's Use, and if such special use, variance
or comparable relief is required, Tenant shall obtain the same (at its sole cost
and expense). Landlord further represents, to its actual knowledge without
independent investigation or inquiry and subject to the foregoing proviso, that
there are no other zoning ordinances or any other prohibitions restricting or
limiting Tenant's Use in any material respect. In addition, Tenant may use all
or any part of the Demised Premises for any lawful purpose then permitted by
local zoning ordinances and the certificate of occupancy, if available;
provided, however, Tenant may not use or occupy the Demised Premises, or
knowingly permit the Demised Premises to be used or occupied (including without
limitation subleasing the Demised Premises or any part thereof or assigning this
Lease to any other party conducting a business other than Tenant's Use) or in
such a manner as to cause the value or usefulness of the Demised Premises, or
any part thereof, substantially to diminish (reasonable wear and tear excepted).
Tenant shall have the exclusive right to use of and shall have full access to
the Demised Premises twenty-four (24) hours per day, seven (7) days per week,
three hundred sixty-five (365) days per year during the term.
B. Tenant may, if Tenant so elects, and for Tenant's sole use, install and
operate within the Building microwave ovens and install and operate within the
Building vending machines to dispense hot and cold beverages, ice cream, candy,
food and cigarettes; such machines shall be maintained in a neat and sanitary
condition and shall comply with all applicable laws and ordinances. Tenant shall
also have the right to use, install and operate within the Building, all
telecommunication lines and other telecommunication and electronic facilities
relating to services to be provided to Tenant and its subtenants and Landlord
agrees to provide all necessary easements upon the Demised Premises reasonably
required by said service provider. Upon termination of the Lease, and if so
requested by Landlord, Tenant shall, at its sole cost and expense, in a good and
workmanlike manner and in as expeditious a manner as possible, remove any or all
such items from the Demised Premises, to the extent required by Landlord. Tenant
further agrees to repair any damage to the Demised Premises caused by the
removal of such items. In connection with any easements granted hereunder to
service providers, Landlord reserves the right to condition any such grant upon
receipt of acknowledgment from the relevant service provider(s) that such
service provider agrees to vacate the easement, and relinquish all of its rights
in the Demised Premises, effective upon the termination of the Lease.
Notwithstanding anything contained herein to the contrary, if the Lease is in
full force and effect as of the thirteenth (13th) anniversary of the
Commencement Date and Tenant is not then in default
7
<PAGE>
hereunder, Landlord waives its rights hereunder to require Tenant to remove from
the Demised Premises any or all of the items referred to above, upon termination
of this Lease.
6. Condition of Demised Premises. Landlord shall construct and Tenant
shall reasonably accept Landlord's Improvements in accordance with the Plans. As
of the Commencement Date, Landlord's Improvements shall be in good working order
and condition and, subject to the items on or to be inserted on the punchlist,
constructed in substantial accordance with the Plans.
7. Maintenance and Repairs.
A. Except as otherwise provided herein, during the term of this Lease,
Tenant shall, at Tenant's sole expense, keep the Demised Premises in good
working order, condition and repair and in compliance with all applicable laws
and shall perform all routine maintenance thereof and all necessary repairs
thereto, interior and exterior, structural and nonstructural ordinary and
extraordinary, foreseen or unforeseen, of every nature, kind and description.
When used in this Paragraph 7, "repairs" shall include all necessary
replacements, renewals, alterations, additions and betterments. If Tenant cannot
keep the Demised Premises or any portion thereof in good working order,
condition and repair, then Tenant shall replace the same in a first-class
manner. Tenant shall comply with manufacturers' recommended schedules for
warranty work. Tenant shall furnish its own cleaning services. All repairs and
replacements made by Tenant shall be at least equal in quality to the original
work and shall be made by Tenant in accordance with all applicable laws. The
necessity for or adequacy of maintenance, repairs and replacements shall be
measured by the standards which are appropriate for improvements of similar
construction and class, provided that Tenant shall in any event make all repairs
and replacements necessary to avoid any structural damage or other damage or
injury to the Demised Premises.
B. Notwithstanding the provisions of Paragraph 7.A., and Tenant's
obligations to pay for all repairs, in the event that at any time during the
term of this Lease after the expiration of the twentieth (20th) Lease Year
(commencing with the Third Extension Term), Tenant reasonably determines that
capital expenditures are required to be expended by Tenant in connection with
maintaining,, repairing or replacing the roof or structural components of the
Building, or replacing the parking areas, Building plumbing, electrical heating,
ventilation, or cooling equipment, sprinkler systems, or making any other
capital expenditure required by subsequent law (any such capital expenditure
being herein referred to as a "Specified Capital Item"), then the Tenant shall
submit to Landlord a proposed budget for such capital expenses for the Specified
Capital Items and obtain Landlord's prior written approval thereof, which
approval shall not be unreasonably withheld or delayed. Upon Tenant's obtaining
Landlord's prior written approval of such Specified Capital Items and Tenant
completing such work in accordance with the requirements set forth in this Lease
then and in that event, the Landlord agrees that it shall reimburse Tenant for
an amount ("Reimbursement Amount") equal to the actual costs incurred in
connection with the Specified Capital Item previously approved by Landlord and
multiplied by a fraction, the numerator of which is the portion of the useful
life of such Specified Capital Items remaining after the then existing term and
the denominator of which is the useful life of such Specified Capital Item
(i.e., by way of example, in the event that the approved cost for an approved
Specified Capital Item was One Thousand Dollars ($1,000) and the useful life of
such Specified Capital Item was eight (8) years and such work was commenced at
the end of the
8
<PAGE>
twentieth (20th) Lease Year, then in such event, Landlord should reimburse
Tenant for Five Hundred Dollars ($500) as the Reimbursement Amount. The "useful
life" of a Specified Capital Item shall be determined using the United States
Internal Revenue Service standard depreciation schedule in effect on the date
that the applicable capital expenditure is made. Notwithstanding anything
contained herein to the contrary, in the event that the Tenant exercises its
option to extend the term of the Lease, then simultaneous with the exercise of
such renewal option, the Tenant shall pay to Landlord an amount equal to the
difference between the Reimbursement Amount and the amount Landlord would have
paid as a Reimbursement Amount had the term been extended by the Extension Term
at the time such Specified Capital Item was commenced (i.e., by way of example,
in the event that the Specified Capital Item was One Thousand Dollars ($1,000)
and that the useful life of the Specified Capital Item was eight (8) years, with
such work having been commenced at the end of the twentieth (20th) Lease Year,
whereby Landlord reimbursed Tenant a Reimbursement Amount of Five Hundred
Dollars ($500), then simultaneous with the exercise of its option to extend the
Term for the Fourth Extension Term, the Tenant would pay to Landlord an amount
equal to Five Hundred Dollars ($500)). The allocation of the costs of Specified
Capital Items as set forth in this Paragraph 7.B. shall not relieve Tenant of
Tenant's maintenance and repair obligation sunder this Lease.
8. Alterations. Tenant may install tenant finishes in the Demised
Premises and make interior alterations, additional installations, modifications,
substitutions, improvements and decorations (collectively, "Alterations") in and
to the Demised Premises, subject only to the following conditions:
(i) any Alterations shall be made at Tenant's sole cost and expense so
that the Demised Premises shall at all times be free of liens for labor and
materials supplied to the Demised Premises;
(ii) without the prior written approval of Landlord, Tenant shall make
no Alterations (x) which are structural in nature or adversely affect in
any way the structure of the Demised Premises; or (y) which adversely
affect or could render void or invalidate any Warranties under this Lease.
In addition, without the prior written approval of Landlord, Tenant shall
make no Alterations to any portion of the exterior or elevation of the
Building.
(iii) any Alterations shall be performed in a good and workmanlike
manner and in compliance with all applicable laws and requirements of
governmental authorities having jurisdiction and applicable insurance
requirements and shall not violate any term of any agreement or restriction
to which the Demised Premises are subject;
(iv) Tenant, at its sole cost and expense, shall cause its contractors
to maintain builder's risk insurance and such other insurance (including,
without limitation, workers compensation insurance) as is then customarily
maintained for such work, all with insurers licensed by the State of
California;
(v) At least fifteen (15) days prior to Tenant's commencement of any
Alterations costing in excess of One Million Dollars ($1,000,000.00), the
plans and specifications therefor shall be submitted to Landlord for
Landlord's review and
9
<PAGE>
approval, which approval shall not be unreasonably withheld or delayed
provided that the provisions of this subparagraph (v) shall not apply to
initial tenant improvements needed to locate a subtenant in the Demised
Premises; and
(vi) To the extent not inconsistent with the requirement set forth
above, ten shall not be required to obtain Landlord's consent to
Alterations which are a subtenant's initial tenant improvements.
Any Alteration shall, when completed, be of such character as not to reduce
the value or utility of the Demised Premises or the Building to which such
Alteration is made below its value or utility to Landlord immediately before
such Alteration, nor shall such Alteration alter the exterior of the
Improvements or reduce the area or cubic content of the Building, nor change the
character of the Demised Premises or the Building as to use without Landlord's
express written consent.
No change, alteration, restoration or new construction shall be in or
connect the Improvements with any property, building or other improvement
located outside the boundaries of the Land, nor shall the same obstruct or
interfere with any existing easement.
Tenant shall notify Landlord in writing 30 days prior to commencing any
alterations, additions or improvements to the Demised Premises so that Landlord
shall have the right to record and post notices of nonresponsibility on the
Demised Premises. Within a reasonable time period prior to commencing the
alterations, additions or improvements, ten shall provide Landlord with copies
of all plans and specifications prepared in connection with any such alteration,
addition or improvement, as well as copies of each material amendment and change
thereto, if and when applicable.
All of Tenant's generators and uninterruptible power supply equipment (but
in no event including the primary HVAC system serving the Building), trade
fixtures, movable partitions, furniture, machinery and furnishings installed by
Tenant or assignees, subtenants or licensees of Tenant shall remain the property
of the owner thereof with the right of removal, whether or not affixed and or
attached to the real estate and the owner thereof shall be entitled to remove
the same or any part thereof during the term or at the end of the term provided
herein, provided that such owner shall repair any damage caused by such removal.
Except as otherwise provided herein, all Alterations made or installed by Tenant
shall remain the Property of Tenant and Tenant shall have the right to remove
the Alterations at any time during the term hereof provided Tenant shall repair
any damage resulting therefrom and leave the Demised Premises in a commercially
reasonable condition. Notwithstanding the foregoing, any Alterations remaining
on the Demised Premises at the end of the term shall become the property of the
Landlord without payment therefor by Landlord, and shall be surrendered to
Landlord at the expiration of the term of this Lease; provided however, if the
Lease term ends prior to the thirteenth (13th) anniversary of the Lease
Commencement Date, if so requested by Landlord, Tenant shall, at its sole cost
and expense and in as expeditious a manner as possible remove any or all of such
Alterations from the Demised Premises, to the extent required by Landlord.
Tenant further agrees to repair any damage resulting therefrom and leave the
Demised Premises in a commercially reasonable condition.
10
<PAGE>
9. Signs.
A. Tenant may install, at its expense and pursuant to the Plans, a
monument identification sign containing Tenant's name at a location depicted on
Exhibit B unless such location would cause a violation of applicable laws in
which event said monument identification sign shall be moved to a location
mutually acceptable to the parties. Tenant shall also have the right to place
any additional signs at the Demised Premises without the prior consent of
Landlord, provided that such sign or signs (a) do not cause any structural
damage or other damage to the Building; (b) do not violate applicable
governmental laws, ordinances, rules or regulations; (c) do not violate any
existing restrictions affecting the Demised Premises; and (d) are compatible
with the architecture of the Building and the landscaped area adjacent thereto.
Tenant shall remove all signage from the Demised Premises at the end of the
term.
B. Landlord may place signs on the Demised Premises identifying Tenant
prior to the Construction Completion Date, provided Tenant has approved each
sign, such approval not to be unreasonably withheld.
10. Services.
A. Landlord shall provide all utility equipment, distribution systems,
fixtures and parts to the Demised Premises in accordance with the Plans, and
shall in all other respects prepare the Demised Premises to accept all utilities
to be used by Tenant during the term of the Lease as contemplated by the Plans
including all connection, tap-in and impact fees, any charges for the
underground installation of electric, gas or other utilities or services, and
other charges relating to the extension of or change in the facilities necessary
to provide the Demised Premises with adequate utilities services. Tenant shall
contract for and pay directly or the cost of usage of all utilities including
all charges for water, heat, gas, light, garbage, electricity, telephone,
sewage, steam, power or other public or private utility services. If after
Landlord's installation of the utility systems required to be provided herein,
any bond, charge or fee is required by the state in which the Demised Premises
are located, or any city or other agency, subdivision, or instrumentality
thereof, or by any utility company furnishing services or utilities to the
Demised Premises, as a condition precedent to continuing to furnish utilities or
services to the Demised Premises, such bond, charge or fee shall be deemed to be
a utility charge payable by Tenant. To the extent existing utility easements on
the Demised Premises are not sufficient to provide utility and communication
services to the Demised Premises for Tenant's use, Landlord agrees to grant
additional easements to utility providers, including telecommunication and
electronic service providers, if reasonably required by Tenant.
B. The Demised Premises shall include all of the improvements shown on the
Site Plan, including, without limitation, exclusive use of the paved parking as
set forth on the Site Plan.
C. Tenant acknowledges that any one or more of the services provided for
in Paragraph 10 hereof may be interrupted or suspended by reason of accident,
repair, alterations or improvements necessary to be made, strike, lockout,
misuse or neglect by Tenant or Tenant's agents, employees or invitees, or by
shortages of fuel or other energy supplies to be provided by public or private
utilities or supplies or by other matters, and Landlord shall not be liable to
11
<PAGE>
Tenant therefore, nor shall Tenant have any right to terminate the Lease or
other rights against Landlord in the event of a failure, interruption or
suspension of any of the aforesaid services.
11. Compliance with Law.
A. Landlord covenants that the Demised Premises (except trade fixtures,
equipment, machinery or any other item constructed or installed by Tenant) will
materially conform as of the Commencement Date to any applicable laws, orders,
statutes, ordinances, rules, regulations and requirements of federal, state and
municipal governments, including, without limitation, all applicable rules and
regulations of the Board of Fire Underwriters and any requirements of the
certificate of occupancy or any permit with respect to the Demised Premises and
the sidewalks, curbs, roadways, alleys, entrances or other facilities adjacent
or appurtenant thereto. Landlord shall be responsible for procuring building and
other permits and licenses necessary for construction of Landlord's
Improvements.
B. Tenant shall throughout the term of this Lease, at ten's sole cost,
materially comply with or remove or cure any violation of any applicable laws,
orders, statutes, ordinances, rules, regulations and requirements of federal,
state and municipal governments, including, without limitation, any applicable
laws, orders, statutes, ordinances, rules, regulations and requirements of any
federal, state or local government relating to occupational safety and health
(collectively, the "OSHA Regulations"), all applicable rules and regulations of
the Board of Fire Underwriters and any requirements of the certificate of
occupancy or any permit with respect to the Demised Premises and the sidewalks,
curbs, roadways, alleys, entrances or railroad track facilities adjacent or
appurtenant thereto, and whether the compliance, curing or removal of any such
violation and the costs and expenses necessitated thereby shall have been
foreseen or unforeseen, ordinary or extraordinary, and whether or not the same
shall be presently within the contemplation of Landlord or Tenant or shall
involve any change of governmental policy, or require structural or
extraordinary repairs, alterations or additions by Tenant and irrespective of
the costs thereof; provided, however, that Landlord shall be responsible, at
Landlord's sole cost, to make all repairs needed for the Demised Premises to
comply with all laws if said repair is required within one (1) years after the
Commencement Date and is necessary due to a defect in the construction of the
Landlord's Improvements including without limitation, a failure to construct the
Landlord's Improvements so that the Demised Premises are in compliance with all
laws as of the Commencement Date. Tenant, at its sole cost and expense, shall
comply with all agreements, contracts, easements, restrictions, reservations or
covenants, if any, affecting the Demised Premises or hereafter created by Tenant
and consented to, in writing, by Tenant or requested, in writing, by Tenant.
Tenant shall also comply with, observe and perform all provisions and
requirements of all policies of insurance at any time in force with respect to
the Demised Premises and shall comply with all development permits issued by
governmental authorities issued in connection with development of the Demised
Premises. Tenant shall procure and maintain all permits and licenses required
for the transaction of Tenant's business at the Demised Premises, including with
limitation, any special use permit, zoning variance or comparable zoning relief
necessary for Tenant's Use.
12
<PAGE>
12. Landlord's Title, Authority, and Quiet Enjoyment: Tenant's Authority.
A. Landlord represents that it will have, as of the Commencement Date,
marketable fee simple title to the Demised Premises, subject to the exceptions
to title currently encumbering the Demised Premises as described in Exhibit H,
and any additional exceptions to title created in connection with Landlord's
acquisition or development of the Demised Premises, or financing of such
acquisition or development (collectively referred to herein as the "Permitted
Exceptions"). Landlord represents that any such additional exceptions to title
created in connection with Landlord's acquisition or development of the Demised
Premises or financing of such acquisition or development shall not materially
interfere with Tenant's intended use of the Demised Premises. Any lien claims
properly bonded over or insured over by title insurance shall be deemed to be
Permitted Exceptions hereunder.
B. Landlord represents and warrants that it has full and complete
authority to enter into this Lease under all of the terms, conditions and
provisions set forth herein, and so long as Tenant keeps and substantially
performs each and every term, provision and condition herein contained on the
part of Tenant to be kept and performed, Tenant shall peacefully and quietly
enjoy the Demised Premises without hindrance or molestation by Landlord or by
any other person claiming by, through or under Landlord, subject to the terms of
the Lease. Without limiting the foregoing, Landlord covenants to perform all
obligations to be performed by Landlord and to pay as and when due all amounts
to be paid by Landlord under any mortgage, deed of trust, ground lease or other
instrument encumbering the Demised Premises. Each individual executing this
Lease on behalf of Landlord represents and warrants to Tenant that he or she is
duly authorized to do so.
C. Tenant represents and warrants that it has full and complete authority
to enter into this Lease under all of the terms, conditions and provisions set
forth herein.
D. Tenant hereby approves the condition of Landlord's title to the Demised
Premises. This Lease shall be subject to the Permitted Exception sand Landlord
shall not permit or cause any easements, covenants, restrictions, conditions or
other changes in Landlord's title which would materially and adversely impact
Tenant's Use. Landlord shall notify Tenant in writing prior to permitting or
causing any easements, covenants, restrictions, or conditions to be placed of
record.
13. Subordination. The priority of this Lease and the leasehold estate of
Tenant created hereunder are and shall be subject and subordinate to the lien of
any mortgage, deed of trust, sale-leaseback, ground lease or similar
encumbrance, whether such encumbrance is placed against the fee or leasehold
estate, affecting the Demised Premises and to all renewals, modifications,
consolidations, replacements and extensions thereof, and advances thereunder;
provided, however, with respect to any mortgage, deed of trust, sale-leaseback,
ground lease or similar encumbrance such subordination shall be subject to
receipt by Tenant of a nondisturbance agreement in form reasonably required by
any such lienholder or ground Lessor (collectively, a "Mortgagee") and
reasonably acceptable to Tenant. Tenant agrees at any time hereafter, upon
twenty (20) days prior written notice, to execute and deliver any instruments,
releases or other documents that may reasonably be required for the purpose of
subjecting and subordinating this Lease, as above provided, to the lien of any
such mortgage, deed of trust, ground lease, sale-
13
<PAGE>
leaseback or similar encumbrance in a form reasonably acceptable to Tenant and
the holder of such mortgage, provided said subordination provides that all
insurance proceeds and condemnation awards will be made available for the
restoration of the Demised Premises, as provided herein, and that Tenant's
rights hereunder will not be disturbed unless Tenant is in default beyond all
applicable cure periods. Any fee which Landlord's lender or ground lessor may
charge for such agreement shall be paid by Landlord.
In the event of any act or omission of Landlord constituting a default by
Landlord, Tenant shall not exercise any remedy until Tenant has given Landlord
and any mortgagee, ground lessor or sale-leaseback lessor of the Demised
Premises that has provided Tenant with written notice of its interest in the
Demised Premises and a notice address for each such party a prior thirty (30)
day written notice of such act or omission and until a reasonable period of time
to allow Landlord or the mortgagee, ground lessor or sale-leaseback lessor to
remedy such act or omission shall have elapsed following the giving of such
notice; provided, however, if such act or omission cannot, with due diligence
and in good faith, be remedied within such thirty (30) day period, then Landlord
or any such mortgagee, ground lessor or sale-leaseback lessor shall be allowed
such further period of time as may be reasonably necessary provided that it
commence remedying the same with due diligence and in good faith within said
thirty (30) day period.
If any Mortgagee shall succeed to the rights of Landlord under this Lease
or to ownership of the Demised Premises, whether through possession or
foreclosure or the delivery of a deed to the Demised Premises, then, upon
written request of such mortgagee so succeeding to Landlord's rights hereunder,
Tenant shall attorn to and recognize such mortgagee, ground lessor or sale-
leaseback lessor as Tenant's landlord under this Lease, and shall promptly
execute and deliver any instrument that such mortgagee may reasonably request to
evidence such attornment (whether before or after making of the mortgage, ground
lease or sale-leaseback lease). In the event of any other transfer of Landlord's
interest hereunder, upon the written request of the transferee and Landlord,
Tenant shall attorn to and recognize such transferee as Tenant's landlord under
this Lease and shall promptly execute and deliver any instrument that such
transferee and Landlord may reasonably request to evidence such attornment.
14. Assignment and Sublease. Tenant, if there is no Material Breach (as
herein defined) by Tenant hereunder, shall have the right to assign this Lease
or to sublease all or any portion of the Demised Premises, without Landlord's
written consent in accordance with the terms of this Paragraph 14.
Tenant may assign this Lease or sublet the Demised Premises to an affiliate
or subsidiary more than fifty percent (50%) of the voting stock of which is
owned directly or indirectly by the direct or remote parent of Tenant (without
Landlord's consent, upon prior written notice to Landlord) and further Tenant'
interest in this Lease may be assigned to and assumed by a successor to Tenant
pursuant to a purchase of all or substantially all of the assets of Tenant in
connection with the sale of such assets or to any entity which acquires all of
Tenant's capital stock (without Landlord's consent upon prior written notice to
Landlord).
Any assignment or sublease shall require the assignee or subtenant to
comply with all terms of this Lease except for any sublease term, which shall be
at Tenant's discretion (but in no event extend beyond the term of this Lease),
and a copy of such sublease or assignment shall be
14
<PAGE>
delivered to Landlord at least ten (10) days prior to the commencement of such
sublease or assignment.
Any assignee shall assume, by instrument in form and content satisfactory
to Landlord, the due performance of all of Tenant's obligation sunder this
Lease, including any accrued obligations at the time of the effective date of
the assignment, and such assumption agreement shall state that the same is made
by the assignee for the express benefit of Landlord as a third party beneficiary
thereof.
Each sublease permitted by this Paragraph 14 shall be subject and
subordinate to all of the terms, covenants and conditions of this Lease and to
all of the rights of Landlord hereunder; and in the event this Lease shall
terminate before the expiration of such sublease, the sublessee thereunder will,
at Landlord's option, attorn to Landlord and waive any rights the sublessee may
have to terminate the sublease or to surrender possession thereunder, as a
result of the termination of this Lease.
Tenant agrees to pay on behalf of Landlord any and all costs of Landlord or
otherwise occasioned by such assignment or subletting, including without
limitation, the cost of any alteration, addition, improvement or other
renovation or refurbishment to the Demised Premises made in connection with such
assignment or subletting and any cost imposed by any governmental authority in
connection with any of the foregoing.
Any assignment or subletting under this Paragraph 14 shall not relieve
Tenant (or any guarantor of Tenant's obligations under the Lease or any
assignee) of its obligations hereunder. Any assignment or subletting of this
Lease which is not in compliance with the provisions of this Paragraph 14 shall
be of no effect and void. Except as permitted in this Paragraph 14, Tenant shall
not transfer, sublet, assign or otherwise encumber its interest in the Lease or
the Demised Premises, unless consented to by Landlord.
No assignment or subleasing hereunder shall relieve Tenant from any of
Tenant's obligation sin this Lease contained.
All profits from any such assignment or subletting shall be the property of
Tenant and not Landlord.
15. Lease Extension. If this Lease shall not have been terminated pursuant
to any provisions hereof and there is no Material Breach (as defined herein) by
Tenant hereunder at the time set for exercise of the Extension Terms (as herein
defined) and at the time set for commencement thereof, then Tenant may, at
Tenant's option, extend the term of this Lease for five (5) successive
additional terms of four (4) years each (each an "Extension Term," collectively
the "Extension Terms") commencing on the expiration of the original term, or the
immediately preceding Extension Term, as the case may be. Tenant may exercise
such option by giving Landlord written notice at least ten (10) months prior to
the expiration of the original or the immediately preceding Extension Term, as
the case may be. Upon the giving by Tenant to Landlord of such written notice
and the compliance by Tenant with the foregoing provisions of this Paragraph 15,
this Lease shall be deemed to be automatically extended upon all the
15
<PAGE>
Covenants, agreements, terms, provisions and conditions set forth in this Lease,
except that Rent for each such Extension Term shall be as provided on Exhibit D.
If Tenant fails or omits to so give to Landlord the written notice referred
to above, Landlord shall provide Tenant with written notice of Tenant's failure
to exercise the Extension Term, and upon receipt of such notice, Tenant shall be
allowed fifteen (15) days to exercise the extension option allowed for herein.
If Landlord fails to provide such notice, Tenant's renewal option shall expire
upon the expiration of the then current term. Failure to respond to Landlord's
notice within such fifteen (15) days shall be deemed to be a waiver by Tenant of
its extension option hereunder.
16. Impositions.
A. Tenant covenants and agrees to pay during the term of this Lease, as
Additional Rent, before any fine, penalty, interest or cost may be added thereto
for the nonpayment thereof, all impositions described herein that accrue on or
after the Commencement Date, which include without limitation, all real estate
taxes, special assessments, water rates and charges, sewer rates and charges,
including any sum or sums payable for future sewer or water capacity increases,
charges for public utilities, street lighting, excise levies, licenses, permits,
inspection fees, other governmental charges, and all other charges or burdens of
whatsoever kind and nature (including costs, fees, and expenses of complying
with any restrictive covenants or similar agreements to which the Demised
Premises are subject), incurred in the use, occupancy, ownership, operation,
leasing or possession of the Demised Premises, without particularizing by any
known name or by whatever name hereafter called, and whether any of the
foregoing be general or special, ordinary or extraordinary, foreseen or
unforeseen (all of which are sometimes herein referred to as "Impositions"),
which at any time during the term may have been or may be assessed, levied,
confirmed, imposed upon, or become a lien on the Demised Premises, or any
portion thereof, or any appurtenance thereto, rents or income therefrom, and
such easements or rights as may now or hereafter by appurtenant to appertain to
the use of the Demised Premises.
B. If, at any time during the term of this Lease, any method of taxation
shall be such that there shall be levied, assessed or imposed on Landlord, or on
the Basic Rent or Additional Rent, or on the Demised Premises or on the value of
the Demised Premises, or any portion thereof, a capital levy, sales or use tax,
gross receipts tax or other tax on the rents received therefrom, or a franchise
tax, or an assessment, levy or charge measured by or based in whole or in part
upon such rents or value, Tenant covenants to pay and discharge the same, it
being the intention of the parties hereto that the rent to be paid hereunder
shall be paid to Landlord absolutely net without deduction or charge of any
nature whatsoever foreseeable or unforeseeable, ordinary or extraordinary, or of
any nature, kind or description, except as in this Lease otherwise expressly
provided. Nothing in this Lease contained shall require Tenant to pay any
municipal, state or federal net income or excess profits taxes assessed against
Landlord, or any municipal, state or federal net income or excess profits taxes
assessed against Landlord, or any municipal, state or federal capital levy,
estate succession, inheritance or transfer taxes of Landlord, or corporation
franchise taxes imposed upon any corporate owner of the fee of the Demised
Premises.
C. Tenant covenants to furnish Landlord, within 30 days after the date
upon which an Imposition or other tax, assessment, levy or charge is payable by
Tenant, official receipts of
16
<PAGE>
the appropriate taxing authority, or other appropriate proof satisfactory to
Landlord, evidencing the payment of the same. The certificate, advice or bill of
the appropriate official designated by law to make or issue the same or to
receive payment of any imposition or other tax, assessment, levy or charge may
be relied upon by Landlord as sufficient evidence that such Imposition or other
tax, assessment, levy or charge is due and unpaid at the time of the making or
issuance of such certificate, advice or bill, unless Tenant provides Landlord
with evidence to the contrary.
D. At Landlord's written demand after any Event of Default (as defined in
Section 20 hereinafter) and for as long as such Event of Default is uncured, or
upon the request of any Mortgagee of the Demised Premises, (but only after an
Event of Default and for as long as such Event of Default is uncured) Tenant
shall pay to Landlord the known or estimated yearly real estate taxes and
assessments payable with respect to the Demised Premises in monthly payments
equal to one-twelfth of the known or estimated yearly real estate taxes and
assessments next payable with respect to the Demised Premises. From time to time
Landlord may re-estimate the amount of real estate taxes and assessments, and in
such event Landlord shall notify Tenant, in writing, of such re-estimate and fix
future monthly installments for the remaining period prior to the next tax and
assessment due date in an amount sufficient to pay the re-estimated amount over
the balance of such period after giving credit for payments made by Tenant on
the previous estimate. If the total monthly payments made by Tenant pursuant to
this Paragraph 16D shall exceed the amount of payments necessary for said taxes
and assessments, such excess shall be credited on subsequent monthly payments of
the same nature; but if the total of such monthly payments so made under this
paragraph shall be insufficient to pay such taxes and assessments when due, then
Tenant shall pay to Landlord such amount as may be necessary to make up the
deficiency.
E. Tenant shall have the right at its own expense to contest the amount or
validity, in whole or in part, of any Imposition by appropriate proceedings
diligently conducted in good faith, but only after Tenant provides Landlord or
the Mortgagee reasonable security, or Tenant makes payment of such Imposition,
unless such payment, or a payment thereof under protest, would operate as a bar
to such contest or interfere materially with the prosecution thereof, in which
event, notwithstanding the provisions of Paragraph 16A hereof Tenant may
postpone or defer payment of such Imposition if neither the Demised Premises nor
any portion thereof would, by reason of such postponement or deferment, be in
danger of being forfeited or lost, and (b) Tenant is not then in Material Breach
of this Lease. Upon the termination of any such proceedings, Tenant shall pay
the amount of such Imposition or part thereof, if any, as finally determined in
such proceedings, the payment of which may have been deferred during the
prosecution of such proceedings, together with any costs, fees, including
attorney's fees, interest, penalties, fines and other liability in connection
therewith, and upon such payment Landlord shall return all amounts or
certificates deposited with it in respect to the contest of such Imposition, as
aforesaid, or, at the written direction of Tenant, Landlord shall make such
payment out of the funds on deposit with Landlord and the balance, if any, shall
be returned to Tenant. Tenant shall be entitled to the refund of any Imposition,
penalty, find and interest thereon received by Landlord which have been paid by
Tenant or which have been paid by Landlord but for which Landlord has been
previously reimbursed in full by Tenant. Landlord shall not be required to join
in any proceedings referred to in this Paragraph 16E unless the provisions of
any law, rule or regulation at the time in effect shall require that such
proceedings be brought by or in the name of Landlord, in which event Landlord
shall join in such proceedings
17
<PAGE>
or permit the same to be brought in Landlord's name upon compliance with such
conditions as Landlord may reasonably require. Landlord shall not ultimately be
subject to any liability or the payment of any fees, including attorney's fees,
costs and expenses in connection with such proceedings. Tenant agrees to pay all
such fees (including reasonable attorney's fees), costs and expenses or, on
demand, or make reimbursement to Landlord for such payment, Of Landlord is
provided a certificate of deposit or other interest bearing instrument as
security for the payment of the contested Imposition, during the time when any
such certificate of deposit or other interest bearing instrument is on deposit
with Landlord, and prior to the time when the same is returned to Tenant or
applied against the payment, removal or discharge of Impositions, as above
provided, Tenant shall be entitled to receive all interest paid thereon, if any.
Cash deposits shall not bear interest.
17. Insurance.
A. During the term of this Lease, during any extension thereof, and during
any holdover period, Tenant shall at its cost and expense procure and keep in
force a policy of comprehensive public liability insurance, with limits of not
less than $1,000,000 for injury to any one person, $2,000,000 as to any one
accident, and $100,000 as to property damage, all on a per occurrence basis
which policy shall name Landlord and its managing agent as additional insureds.
A certificate of such insurance shall be delivered to Landlord prior to the
Commencement Date and shall provide that same may not be cancelled or lowered in
amounts without prior written notice of not less than thirty (30) days to
Landlord and Landlord's mortgagee. Notwithstanding the foregoing, Tenant may
insure the foregoing risks under its blanket policy or elect to self-insure such
risks as provided in Paragraph 17E below. Any such liability insurance shall
contain a contractual liability endorsement covering Tenant's indemnification
obligations under this Lease.
B. During the term of this Lease and any extension thereof, Tenant, at its
sole cost and expense, shall obtain and continuously maintain in full force and
effect, policies of insurance covering the Improvements constructed, installed
or located on the Demised Premises naming the Landlord, as loss payee as its
interest may appear, against (a) loss or damage by fire; (b) loss or damage from
such other risks or hazards now or hereafter embraced by an "Extended Coverage
Endorsement,) including, but not limited to, windstorm, hail, explosion,
vandalism, riot and civil commotion, damage from vehicles, smoke damage, water
damage and debris removal; (c) loss for flood if the Demised Premises are in a
designated flood or flood insurance area; (d) loss for damage by earthquake if
the Demised Premises are located in an earthquake-prone area; (e) loss from so-
called explosion, collapse and underground hazards; and (f) loss or damage from
such other risks or hazards of a similar or dissimilar nature which are now or
may hereafter be customarily insured against with respect to improvements
similar in construction, design, general location, use and occupancy to the
Improvements. At all times, such insurance coverage shall be in an amount equal
to 100% of the then "full replacement cost" of the Improvements. "Full
Replacement Cost" shall be interpreted to mean the cost of replacing the
improvements without deduction for depreciation or wear and tear, and it shall
include a reasonable sum for architectural, engineering, legal, administrative
and supervisory fees connected with the restoration or replacement of the
Improvements in the event of damage thereto or destruction thereof. If a
sprinkler system shall be located in the Improvements, sprinkler leakage
insurance shall be procured and continuously maintained by Tenant and Tenant's
18
<PAGE>
sole cost and expense. Tenant shall cause to be inserted in the policy of
insurance required by this Paragraph 17B the so-called "waiver of subrogation"
clause as to Landlord and Landlord's insurer.
C. During the term of this Lease and any extension thereof, TENANT shall
maintain Workman's Compensation Insurance in accordance with the laws of the
State of California.
D. Tenant shall maintain insurance coverage (including loss of use and
business interruption coverage) upon Tenant's business and upon all personal
property of Tenant or the personal property of others kept, stored or maintained
on the Demised Premises against loss or damage by fire, windstorm or other
casualties or causes for such amount as Tenant may desire, and Tenant agrees
that such policies shall contain a waiver of subrogation clause as to Landlord
and Landlord's insurer.
E. Tenant's right to self-insure with respect to liability insurance is
conditioned upon Tenant or Tenant's guarantor maintaining a net work of at least
$100,000,000.00. Tenant shall furnish Landlord written confirmation that Tenant
has elected to self-insure with respect to liability insurance (if that is the
case), and if so, that Tenant's or Tenant's guarantor's net worth is at least
$100,000,000.00 as evidenced by audited financial statements of Tenant or
Tenant's guarantor or an affidavit from Tenant's or Tenant's guarantor's chief
financial officer. If Tenant self-insures with respect to liability insurance,
then Tenant agrees to indemnify, defend, and hold Landlord harmless from and
against any loss, damage, costs, fees (including attorneys, fees), claims,
demands, actions, causes of action, judgements, suits and liability that was or
would have been covered by the insurance policy or policies replaced by self-
insurance and such self-insurance shall not affect the nonliability of Landlord
under Paragraph 17F as to any loss or damage caused by the period described
therein. The indemnification contained in this Paragraph 17E is in addition to,
and not in lieu of, any covenants or obligations of Tenant contained in the
other Paragraphs of this Lease. If Tenant so elects to become a self-insurer
with respect to liability insurance, Tenant shall deliver to Landlord notice in
writing of the required coverages which it is self-insuring setting forth the
amount, limits, and scope of the self-insurance in respect to each type of
coverage self-insured. Tenant, at Landlord's request, shall provide to
Landlord's mortgagee or assignee a certificate satisfactory to such mortgagee or
assignee setting forth the self-insured coverages, if any, and stating that all
losses shall be payable to such mortgagee and/or assignee as its interests may
appear.
Nothing in this Paragraph shall prevent Tenant from taking out insurance of
the kind and in the amount provided for under the preceding paragraphs of this
Paragraph under a blanked insurance policy or policies (certificates thereof
reasonably satisfactory to Landlord shall be delivered to Landlord) which may
cover other properties owned or operated by Tenant as well as the Demised
Premises; provided, however, that any such policy of blanket insurance of the
kind provided for shall specify therein the amounts thereof exclusively
allocated to the Demised Premises or Tenant shall furnish Landlord and the
holder of any fee mortgage with a written statement from the insurers under such
policies specifying the amounts of the total insurance exclusively allocated to
the Demised Premises; and provided, further, however, that such policies of
blanket insurance shall, as respects the Demised Premises, contain the various
provisions required of such an insurance policy by the foregoing provisions of
this Paragraph 17.
19
<PAGE>
F. Tenant hereby releases Landlord (and Landlord's assignees, employees,
agents and servants) and waives any claims it may have against Landlord from any
liability for damage to or destruction of Tenant's trade fixtures, personal
property (including also property under the care, custody, or control of
Tenant), machinery, equipment, furniture, fixtures and business interests on the
Demised Premises, except arising from Landlord's or Landlord's assignees',
employees', agents' or servants' negligence. This Paragraph shall apply
especially, but not exclusively, to damage or destruction caused by the flooding
of basements or other subsurface areas, or by refrigerators, sprinkling devices,
air conditioning apparatus, water, snow, frost, steam, excessive heat or cold,
falling plaster, broken glass, sewage, gas, odors or noise, or the bursting or
leaking of pipes or plumbing fixtures, and shall apply equally, whether any such
damage results from the act or omission of other tenants or occupants in the
Demised Premises or any other persons, and whether such damage be caused by or
result from any of the aforesaid, or shall be caused by or result from other,
circumstances of a similar or dissimilar nature.
G. Tenant shall require each of its contractors and tradespeople to carry
contractors liability/completed operations insurance, in the amounts specified
in Paragraph 17A above, from companies licensed to do business in the State of
California.
H. Upon expiration of the term of this Lease, the unearned premiums upon
any insurance policies or certificates thereof lodged with Landlord by Tenant
shall be payable to Tenant, provided that Tenant shall not then be in default in
keeping, observing or performing the terms and conditions of this Lease.
18. Destruction and Restoration.
A Tenant covenants and agrees that in case of damage to or destruction of
the Improvements after the Commencement Date of the term of this Lease, by fire
or otherwise, Tenant, at its sole cost and expense, shall promptly restore,
repair, replace and rebuild the same as nearly as possible to the condition that
the same were in immediately prior to such damage or destruction with such
changes and alterations (made in conformity with Paragraph 8 hereof) as may be
reasonably acceptable to Landlord or required by law. Tenant shall forthwith
give Landlord such written notice of such damage or destruction upon the
occurrence thereof and specify in such notice, in reasonable detail, the extent
thereof. Such restoration, repairs, replacements, rebuilding, changes and
alterations, including the cost of temporary repairs for the protection of the
Demised Premises, or any portion thereof, pending completion thereof are
sometimes hereinafter referred to as the "Restoration." The Restoration shall be
carried on and completed in accordance with the provisions and conditions of
Paragraphs 8 and 18B hereof. If the net amount of the insurance proceeds (after
deduction of all costs, expenses and fees related to recovery of the insurance
proceeds) recovered by Landlord and held by Landlord and Tenant as co-trustees
is reasonably deemed insufficient by Landlord to complete the Restoration of
such improvements (exclusive of Tenant's personal property and trade fixtures
which shall be restored, repaired or rebuilt out of Tenant' separate funds),
Tenant shall, upon request of Landlord, deposit with Landlord and Tenant, as co-
trustees, a cash deposit equal to the reasonable estimate of the amount
necessary to complete the Restoration of such improvements less the amount of
such insurance proceeds available.
20
<PAGE>
B. All insurance moneys recovered by Landlord and held by Landlord and
Tenant as co-trustees on account of such damage or destruction, less Landlord's
reasonable out-of-pocket costs, if any, to Landlord of such recovery, shall be
applied to the payment of the costs of the Restoration and shall be paid out
from time to time as the Restoration progresses upon the written request of
Tenant, accompanied by a certificate of the architect or a qualified
professional engineer in charge of the Restoration stating that as of the date
of such certificate (a) the sum requested is justly due to the contractors,
subcontractors, materialmen, laborers, engineers, architects, or persons, firms
or corporations furnishing or supplying work, labor, services or materials for
such Restoration, or is justly required to reimburse Tenant or any expenditures
made by Tenant in connection with such Restoration, and when added to all sums
previously paid out by Landlord does not exceed the value of the Restoration
performed to the date of such certificate by all of said parties; (b) except for
the amount, if any, stated in such certificates to be due for work, labor,
services or materials, there is no outstanding indebtedness known to the person
signing such certificate, after due inquiry, which is then due for work, labor,
services or materials in connection with such Restoration, which, if unpaid,
might become the basis of a mechanic's lien or similar lien with respect to the
Restoration or a lien upon the Demised Premises, or any portion thereof; and (c)
the costs, as estimated by the person signing such certificate, of the
completion of the Restoration required to be done subsequent to the date of such
certificate in order to complete the Restoration do not exceed the sum of the
remaining insurance moneys, plus the amount deposited by Tenant, if any,
remaining in the hands of Landlord after payment of the sum requested in such
certificate.
Tenant shall furnish Landlord within thirty (30) days after Tenant's
receipt of each progress payment with evidence reasonably satisfactory to
Landlord that Tenant has paid all bills in respect to any work, labor, services
or materials performed, furnished or supplied in connection with such
Restoration which was covered by the previous progress payment. Landlord shall
not be required to pay out or consent to any additional insurance moneys where
Tenant fails to supply satisfactory evidence of the payment of work, labor,
services or materials performed, furnished or supplied, as aforesaid. If the
insurance moneys in the hands of Landlord and Tenant as co-trustees, and such
other sums, if any, deposited with Landlord and Tenant as co-trustees pursuant
to this Paragraph 18, shall be insufficient to pay the entire costs of the
Restoration, Tenant agrees to pay any deficiency promptly insurer, and provided
further that notwithstanding that the insurance moneys are insufficient to pay
the cost of the Restoration, Tenant shall continue to be liable for full payment
of Base Rent, Additional Rent and any other amounts due and payable hereunder.
Upon completion of the Restoration and payment in full thereof by Tenant,
Landlord shall within a reasonable period of time thereafter, turn over to
Tenant all insurance moneys or other moneys then remaining upon submission of
proof reasonably satisfactory to Landlord that the Restoration has been paid for
in full and the damaged or destroyed Building and other improvements repaired,
restored or rebuilt as nearly as possible to the condition they were in
immediately prior to such damage or destruction, or with such changes or
alterations as may be made in conformity with Paragraphs 8 and 18A hereof.
C. No destruction of or damage to the Demised Premises, or any portion
thereof, by fire, casualty or otherwise shall permit Tenant to surrender this
Lease or shall relieve Tenant form its liability to pay to Landlord the Base
Rent and Additional Rent payable under this Lease
21
<PAGE>
or from any other such obligations under the Lease, and Tenant waives any rights
now or hereafter conferred upon Tenant by present or future law or otherwise to
quit or surrender this Lease or the Demised Premises, or any portion thereof, to
Landlord or to any suspension, diminution, abatement or reduction or rent on
account of any such damage or destruction.
D. Landlord agrees, subject to the provisions of Paragraph 8 and 18
hereof, to in all instances turn over and make available to Tenant all insurance
moneys contemplated by Paragraph 18B hereof.
19. Condemnation.
A. If, during the term of this Lease, the entire Demised Premises shall be
taken as the result of the exercise of the power of eminent domain (hereinafter
referred to as the "Proceedings"), this Lease and all right, title and interest
of Tenant hereunder shall cease and come to an end on the date of vesting of
title pursuant to such Proceedings and Landlord shall be entitled to and shall
receive the total award made in such Proceedings; provided that Tenant shall
have the right to state a claim separate from Landlord's claim against the
condemning authority for Tenant's moving costs and the loss of the bargain of
this Lease, to the extent that such a claim by Tenant does not otherwise reduce
Landlord's award.
In any taking of the Demised Premises, or any portion thereof, whether or
not this Lease is terminated as in this paragraph provided, Tenant shall not be
entitled to any portion of the award for the taking of the Demised Premises or
damage to the Improvements, except as otherwise provided for in Paragraph 19C
with respect to the restoration of the Improvements, or for the estate or
interest of Tenant therein, all such award, damages, consequential damages and
compensation being hereby assigned to Landlord, and Tenant hereby waives any
right it now has or may have under present or future law to receive any separate
award of damages for its interest in the Demised Premises, or any portion
thereof, or its interest in this Lease, expect that Tenant shall have,
nevertheless, the limited right to prove in the Proceedings and to receive any
award which may be made for damages to or condemnation for Tenant's movable
trade fixtures and equipment, and for Tenant's relocation costs in connection
therewith.
B. If, during the initial term of this Lease, or any extension or renewal
thereof, less that the entire Demised Premises, but more than 15% of the floor
area of the Building, or more than 25% of the land area of the Demised Premises,
or more than 20% of the parking spaces, shall be taken in any such Proceeding,
this Lease shall, upon vesting of title in the Proceedings, terminate as to the
portion of the Demised Premises so taken, and Tenant may, at its option,
terminate this Lease as to the remainder of the Demised Premises, Tenant shall
not have the right to terminate this Lease pursuant to the preceding sentence
unless (a) the business of Tenant conducted in the portion of the Demised
Premises taken cannot reasonably be carried on with substantially the same
utility and efficiency in the remainder of the Demised Premises (or any
substitute space securable by Tenant pursuant to clause (b) hereof ) and (b)
Tenant cannot construct or secure or Landlord cannot provide substantially
similar space to the space so taken, on the remainder of the Demised Premises,
or Landlord cannot provide replacement parking spaces on additional property
located in close proximity to the Demised Premises that are reasonably
acceptable to Tenant. Such termination as to the remainder of the Demised
Premises shall be effected by notice in writing given not more than 60 days
after the date of vesting of title
22
<PAGE>
in such Proceedings, and shall specify a date not more than 60 days after the
giving of such notice as the date for such termination. Upon the date specified
in such notice, the term of this Lease, and all right, title and interest of
Tenant hereunder, shall cease and come to an end. If this Lease is terminated as
in this Paragraph 19B provided, Landlord shall be entitled to and shall receive
the total award made in such Proceedings, Tenant hereby assigning any interest
in such award, damages, consequential damages and compensation to Landlord, and
Tenant hereby waiving any right Tenant has now or may have under present or
future law to receive any separate award of damages for its interest in the
Demised Premises, or any portion thereof, or its interest in this Lease except
as otherwise provided in Paragraph 19A. The right of Tenant to terminate this
Lease, as in this Paragraph 19B provided, shall be exercisable only upon
condition that Tenant is not then in default in the performance of any of the
terms, covenants or conditions of this Lease on its part to be performed, and
such termination upon Tenant's part shall become effective only upon compliance
by Tenant with all such terms, covenants and conditions to the date of such
termination. In the event that Tenant elects not to terminate this Lease as to
the remainder of the Demised Premises, the rights and obligations of Landlord
and Tenant shall be governed by the provisions of Paragraph 19C hereof.
C. If 15%, or less, of the floor area of the Building, or 25%, or less, of
the land area of the Demised Premises or 20% or less, of the parking spaces
shall be taken in such Proceedings, or if more than 15% of the floor area of the
Building or more than 25% or the land area of the Demised Premises or more than
20% of the parking spaces is taken (but less than the entire Demised Premises),
and this Lease is not terminated as in Paragraph 19B hereof provided, this Lease
shall, upon vesting of title in the Proceedings, terminate as to the parts so
taken, and Tenant shall have no claim or interest in the award, damages,
consequential damages and compensation, or any part thereof except as otherwise
provided in Paragraph 19A. Landlord shall be entitled to and shall receive the
total award made in such Proceedings, Tenant hereby assigning any interest in
such award, damages, consequential damages and compensation to Landlord, and
Tenant hereby waiving any right Tenant, has now or may have under present or
future law to receive any separate award of damages for its interest in the
Demised Premises, or any portion thereof, or its interest in this Lease except
as otherwise provided in Paragraph 19A. The net amount of the award (after
deduction of all costs and expenses, including attorney's fees), shall be held
by Landlord as trustee and applied as hereinafter provided. Tenant, in such
case, covenants and agrees, at Tenant's sole cost and expense (subject to
reimbursement to the extent hereinafter provided), promptly to restore that
portion of the Improvements on the Demised Premises not so taken to a complete
architectural and mechanical unit for the use and occupancy of Tenant as in this
Lease provided. In the event that the net amount of the award (after deduction
of all costs and expenses, including attorney's fees) that may be received by
Landlord and held by Landlord as trustee in any such Proceedings as a result of
such taking is insufficient to pay all costs of such restoration work, Tenant
shall deposit with Landlord as trustee such additional sum as may be required
upon the written request of Landlord so long as Tenant has participated in the
Proceedings or otherwise provided reasonably adequate assurances to Landlord
that Tenant has the financial resources to fund such additional sum; provided,
however, Landlord shall retain ultimate control over any final settlement or
litigation with the condemning authority, and provided further that
notwithstanding that the net amount of the award may be insufficient to pay all
costs of the restoration work, Tenant shall continue to be liable for payment of
Base Rent, Additional Rent and any other amount due and payable hereunder, which
amounts shall not be abated except as provided in Paragraph 19E below. The
23
<PAGE>
provisions and conditions in Paragraph 8 applicable to changes and alterations
shall apply to Tenant's obligations to restore that portion of the Improvements
to a complete architectural and mechanical unit. Landlord agrees in connection
with such restoration work to apply so much of the net amount of any award
(after deduction of all costs and expenses, including attorney's fees) that may
be received by Landlord and held by Landlord as trustee in any such Proceedings
as a result of such taking to the costs of such restoration work thereof and the
said net award as a result of such taking shall be paid out from time to time to
Tenant, or on behalf of Tenant, as such restoration work progresses upon the
written request of Tenant, which shall be accompanied by a certificate of the
architect or the registered professional engineer in charge of the restoration
by a certificate of the architect of the registered professional engineer in
charge of the restoration work stating that (a) the sum requested is justly due
to the contractors, subcontractors, materialmen, laborers, engineers, architects
or other persons, firms or corporations furnishing or supplying work, labor,
services or materials for such restoration work or as is justly required to
reimburse Tenant for expenditures made by Tenant in connection with such
restoration work, and when added to all sums previously paid out by Landlord as
trustee does not exceed the value of the restoration work performed to the date
of such certificate; and (b) the net amount of any such award as a result of
such taking remaining in the hands of Landlord, together with the sums, if any,
deposited by Tenant with Landlord as trustee pursuant to the provisions hereof,
will be sufficient upon the completion of such restoration work to pay for the
same in full. If payment of the award as a result of such taking, as aforesaid,
shall not be received by Landlord in time to permit payments as the restoration
work progresses (except in the event of an appeal of the award by Landlord),
Tenant shall not be required to proceed with any restoration work until payment
of such award is received by Landlord; provided, however, delay in payment of
such amount shall not release Tenant of its obligation to pay Base Rent,
Additional Rent and other amounts due and payable hereunder during any such
delay and there shall be no abatement of Base Rent, Additional Rent or any other
amounts except as provided in Paragraph 19E below. If Landlord appeals an award
and payment of the award is delayed pending appeal Tenant shall, nevertheless,
perform and fully pay for such work without delay, and payment of the amount to
which Tenant would have been entitled had Landlord how appealed the award (in an
amount not to exceed the net award prior to such appeal) shall be made by
Landlord to Tenant as restoration progresses pursuant to this Paragraph 19C, in
which event Landlord shall be entitled to retain an amount equal to the sum
disbursed to Tenant pursuant to the preceding sentence out of the net award as
and when payment of such award is received by Landlord. Tenant shall also
furnish Landlord as trustee with each certificate hereinabove referred to,
together with evidence reasonably satisfactory to Landlord that there are no
unpaid bills in respect to any work, labor, services or materials performed,
furnished or supplied, or claimed to have been performed, furnished or supplied,
in connection with such restoration work [relating to prior payments made by
Landlord to Tenant], and that no liens have been filed against the Demised
Premises, or any portion thereof. Landlord as trustee shall not be required to
pay out any funds when there are unpaid bills for work, labor, services or
materials performed, furnished or supplied in connection with such restoration
work relating to prior payments made by Landlord to Tenant, or where a lien for
work, labor, services or materials performed, furnished or supplied has been
placed against the Demised Premises, or any portion thereof. Upon completion of
the restoration work and payment in full therefor by Tenant, and upon submission
of proof reasonably satisfactory to Landlord that the restoration work has been
paid for in full and that the Improvements have been restored or rebuilt to a
complete architectural and mechanical unit for the use and occupancy of Tenant
as provided in this Lease, Landlord as trustee shall pay over to Tenant any
portion of the cash deposit furnished by Tenant then remaining; provided,
however, any other amounts awarded
24
<PAGE>
in such Proceedings (and made available for restoration) which remain following
restoration. The Demised Premises shall be the property of Tenant and Landlord
shall have not claim thereto.
D. In the event of any partial termination of this Lease as a result of
any such proceedings, Tenant shall pay to Landlord all Base Rent and all
Additional Rent and other charges payable hereunder with respect tot hat portion
of the Demised Premises so taken in such Proceedings with respect to which this
Lease shall have terminated justly apportioned to the date of such termination.
From and after the date of vesting of title in such Proceedings, Tenant shall
continue to pay the Base Rent and Additional Rent and other charges payable
hereunder, as in this Lease provided, to be paid by Tenant, subject to
abatement, if any, as provided for in Paragraph 19E hereof.
E. In the event of a partial taking of the Demised Premises under
Paragraph 19C hereof, or a partial taking of the Demised Premises under
Paragraph 19B hereof, followed by Tenant's election not to terminate this Lease,
the fixed Base Rent payable hereunder during the period from and after the date
of vesting of title in such Proceedings to the termination of this Lease shall
not be reduced unless Tenant shall have completed the restoration work with its
own funds in accordance with the provisions of the Lease and Landlord shall have
applied the net amount of any award to reduce the indebtedness secured by any
financing encumbering the Demised Premises or otherwise to reduce the amount of
Landlord's Development Costs (as herein defined), in which event fixed Base Rent
payable hereunder shall be reduced to a sum equal to the product of the Base
Rent provided for herein multiplied by a fraction, the numerator of which shall
be Landlord's Development Costs less any amounts so paid to and applied by
Landlord less Tenant's $2,000,000 contribution, and the denominator of which
shall be Landlord's Development Costs less Tenant's $2,000,000 without regard
to any amounts so paid to and applied by Landlord.
F. Anything herein to the contrary notwithstanding, upon the occurrence of
any Proceedings which would otherwise result in a termination of this Lease,
Tenant shall, as a condition precedent to such termination so long as Tenant has
participated in such proceedings, (provided, however, Landlord shall retain
ultimate control over any final settlement or litigation with the condemning
authority), pay to Landlord an amount, reasonably estimated by Landlord, equal
to the excess, if any, of the unamortized portion of Landlord's Development
Costs, less the $2,000,000 referred to below, over the net award to be received
by Landlord after deduction of all costs of the Proceedings. In making the
foregoing calculation, Landlord shall use an interest rate equal to the interest
rate associated with the project financing from time to time during the term of
this Lease. "Landlord's Development Costs" Shall mean and include any and all
amounts incurred by Landlord in connection with the acquisition and development
of the Demised Premises, including, without limitation, consideration paid for
acquisition of the Demised Premises, costs for required off-site improvements,
including relocating electric lines underground, all architectural, engineering,
environmental, land planning and other consulting fees, all title and survey
expenses, any and all fees and expenses associated with procuring construction
and/or other financing for the project, any other costs or expenses that would
not have been incurred by Landlord had Landlord not been involved in the
acquisition of the Demised Premises, and all attorneys' fees associated with any
of the foregoing. A preliminary estimate of Landlord's Development Costs (which
includes Tenant's initial contribution of $2,000,000 as deposited into escrow
under Paragraph 3) is attached hereto and made a part
25
<PAGE>
hereof as Exhibit G; provided, however, the parties agree and acknowledge that
the amounts and categories of costs and expenses set forth on Exhibit G
represent an estimate of such items only and that Landlord anticipates changes
in, additions to and modifications of such items, including, without
limitation, changes, additions and modifications of such items as development
of the project and construction of the Demised Premises progresses including,
without limitation, changes, additions and modifications relating to actual
design and construction costs, and in securing construction and permanent
financing for the project from time to time. The parties agree to update the
estimate provided for in Exhibit G within sixty (60) days after the
Commencement Date and attach the updated Exhibit G initialed and dated by the
parties in place of the Exhibit G attached as of the date hereof.
20. Default by Tenant. The occurrence of any one or more of the following
events shall constitute an "Event of Default" by Tenant:
A. The failure by Tenant to make any payment of rental or any other
payment required to be made by Tenant hereunder, and any interest for late
payment thereof, as and when due, where such failure shall continue for a period
of five (5) days after receipt by Tenant of a written notice thereof from
Landlord.
B. The failure by Tenant to observe or perform any of the covenants,
conditions or provisions of this Lease (other than the failure by Tenant
described in subparagraph E below) where such failure shall continue for a
period of thirty (30) days after receipt by Tenant of written notice thereof
from Landlord; provided, however, that if the nature of Tenant's default is such
that it cannot be cured solely by payment of money (and in the reasonable
judgement of Landlord said default is susceptible to cure) and that more than
thirty (30) days may be reasonably required for such cure, then Tenant shall not
be deemed to be in default if Tenant shall commence such cure within such thirty
(30) day period and shall thereafter diligently prosecute such cure to
completion.
C. (a) the making of any general arrangement or any assignment by Tenant
for the benefit of creditors;
(b) the filing by or against Tenant of a petition to have Tenant
adjudged a bankrupt or a petition of reorganization or arrangement under
any law relating to bankruptcy (unless, in the case of a petition filed
against Tenant, the petition is dismissed within ninety (90) days of the
date filed);
(c) the appointment of a trustee or receiver to take possession of
substantially all of Tenant's assets; and
(d) the attachment, execution or other judicial seizure of
substantially all of Tenant's assets.
D. An assignment or subletting by Tenant in violation of Paragraph 14
hereof.
E. The failure by Tenant in keeping, observing or performing any of the
terms contained in this Lease, other than those referred to in Subparagraphs 14
A, B, C and D above, and which exposes Landlord to criminal liability, and such
default shall continue after written.
26
<PAGE>
notice thereof given from Landlord to Tenant, and Tenant fails to proceed timely
and promptly with all due diligence and in good faith to cure the same and
thereafter to prosecute the curing of such default with all due diligence, it
being intended that in connection with a default which exposes Landlord to
criminal liability that Tenant shall proceed immediately to cure or correct
such condition with continuity and with all due diligence and in good faith.
21. Landlord's Remedies. In the event of any Material Breach of this
Lease by Tenant, then Landlord, in addition to other rights or remedies it may
have, shall have the right to terminate this Lease, or without terminating this
Lease, terminate Tenant's right to possession of the Demised Premises, and in
either event Tenant shall immediately surrender possession of the Demised
Premises to Landlord and if Tenant fails to do so, Landlord may, without
prejudice to any other remedy it may have for possession or arrearage of
rentals, enter upon and take possession of the Demised Premises and expel or
remove Tenant and any other person who may be occupying the Demised Premises or
any part thereof, with or without legal proceedings, by force if necessary,
without being liable for prosecution or any claim or damage therefor. In such
event, Landlord shall be entitled to recover from Tenant all reasonable damages
incurred by Landlord by reason of Tenant's default, including without
limitation, the cost of recovering possession of the Demised Premises, expenses
of reletting including reasonable renovation and alteration of the Demised
Premises, reasonable attorney's, fees, real estate commissions, and any other
sum of money, late charges and damages caused by Tenant to Landlord. As used
herein, "Material Breach" shall mean any breach by Tenant in any of the terms
and conditions of this Lease which upon an Event of Default would have a
material and adverse impact of any kind upon Landlord and/or the Demised
Premises, as opposed to a technical breach by Tenant which is de minimis in
nature.
If Tenant's right to possession of the Demised Premises is terminated
without termination of the Lease, Landlord shall be entitled to enforce all of
Landlord's rights and remedies under the Lease, including the right to recover
the rent as it becomes due hereunder. Should Landlord elect to relet the
Demised Premises or any part thereof, Landlord may do so for such term or terms
and at such rental or rentals and upon such other terms and conditions as
Landlord may deem appropriate. Rental and other amounts received by Landlord in
connection with such reletting shall be applied against the amounts due from
Tenant hereunder after deducting any expenses insured by Landlord with respect
to such reletting as provided above. Tenant shall pay any deficiency to
Landlord. Such deficiency shall be calculated on a cumulative basis with all
excess payments received by Landlord from such reletting to be applied against
future amounts due from Tenant and any deficiencies to be paid monthly. No such
reentry or taking possession of the Demised Premises by Landlord shall be
construed as an election on its part to terminate this Lease, unless a written
notice of such intention by given to Tenant, in which event Tenant's obligations
to Landlord shall forthwith cease, or unless the termination thereof be decreed
by a court of competent jurisdiction.
In the event Landlord terminates this Lease in accordance with this
Paragraph, then, Tenant shall be liable and shall pay to Landlord, the sum of
all rent and other payments owed to date to Landlord, all sums owed to date to
third parties (including without limitation, all Impositions) hereunder accrued
to the date of such termination, all reasonable amounts required to be spent by
Landlord to fulfill any of Tenant's obligations which Tenant did not fulfill
prior to termination by Landlord, plus, as damages, an amount equal to the
present value discounted at
27
<PAGE>
ten percent (10%) of (i) the total rental payments hereunder for the remaining
portion of the term of the Lease, calculated as if such term expires on the date
set forth in paragraph 2, unless Tenant has extended this Lease, in which case
such calculation shall be as if the term expires on the final day of the
extension term then in effect, less (ii) the fair market rental value of the
Demised Premises for such remaining period. Nothing herein contained shall
limit or prejudice the right of Landlord to prove for and obtain, as damages by
reason of such expiration or termination, an amount equal to the maximum allowed
by any statute or rule of law in effect at the time when, and governing the
proceedings in which, such damages are to be proved, whether or not such amount
be greater, equal to or less than the amount of the difference referred to
above.
Landlord shall have the obligation to mitigate its damages to the extent
required by state law.
In addition to the aforesaid remedies, Landlord shall be entitled to pursue
any other remedy now or hereafter available to Landlord at equity or under the
laws or judicial decisions of the state where the demised Premises is located or
by statute or otherwise. All rights and remedies of Landlord herein enumerated
shall be cumulative, and the exercise or the commencement of the exercise by
Landlord of any one or more of such rights or remedies should not preclude the
simultaneous or later exercise by Landlord of any or all other rights or
remedies. Tenant shall pay, upon demand, all of Landlord's costs, including
reasonable attorneys' fees and court costs, incident to the enforcement of
Tenant's obligations hereunder. A receipt by Landlord of rent with knowledge of
the breach of any covenant hereof (other than breach of the obligation to pay
the portion of such rent paid) shall not be deemed a waiver of such breach, and
no waiver by Landlord of any provisions of this Lease shall be deemed to have
been made unless expressed in writing and signed by Landlord. Without limiting
the generality of the foregoing, no failure by Landlord to insist upon the
performance of any of the terms of this Lease or to exercise any right or
remedy consequent upon a breach thereof shall constitute a waiver of such breach
or any of the terms of this Lease, and no express waiver shall affect any
default other than the default specified in the express waiver and that only for
the time and to the extent therein stated. One or more waivers by Landlord
shall not be construed as a waiver of a subsequent breach of the same covenant,
term or condition. In addition to other remedies in this Lease provided,
Landlord shall be entitled to seek a restraint by injunction of the violation or
attempted or threatened violation of the covenants, conditions and provisions of
this Lease.
22. Default by Landlord. The following shall constitute a "Material
Breach" by Landlord:
The failure by Landlord to observe or perform any of the covenants,
conditions or provisions of this Lease where such failure shall continue for a
period of thirty (30) days after receipt by Landlord of written notice thereof
from Tenant; provided , however, that if the nature of Landlord's default is
such that it cannot be cured solely by payment of money and that more than
thirty (30) days may be reasonably required for such cure, then Landlord shall
not be deemed to be in default if Landlord shall commence such cure within such
thirty (30) day period and shall thereafter diligently prosecute such cure to
completion.
23. Tenant's Remedies. In the event of any Material Breach of this Lease
by Landlord, then Tenant in addition to other rights or remedies it may have at
law or in equity
28
<PAGE>
subject to the terms of this Lease), at Tenant's sole option, may perform such
obligations of Landlord provided that Tenant has furnished to any party having
a recorded mortgage, deed of trust, ground lease or similar lien against the
Demised Premises (for which Tenant has received written notice) with written
notice of such default and such party has failed to cure the same within the
limits prescribed herein for Landlord to cure such default, and Tenant may
invoice Landlord for the costs and expenses thereof, which invoice Landlord
shall promptly pay. Notwithstanding the foregoing, despite such notice and
expiration of such sure period, no rent or other payments due from Tenant may
be offset by Tenant, and Tenant shall have no right to perform any obligation
of Landlord unless such performance by Tenant is necessary to prevent imminent
injury or damage to persons or Tenant's property.
24. Delivery of Executed Lease. Deleted by intent of parties.
25. Termination. Deleted by intent of parties.
26. Notices. All notices shall be sent by registered mail, return receipt
requested, or by recognized overnight courier providing proof of delivery, to
the following addresses;
To Landlord: To Tenant:
Sunnyvale Limited Partnership First Data Merchant Services
Ridge Sunnyvale, Inc., Corporation
c/o Ridge Capital Corporation Attention: David L. Schlapbach,
Attention: James G. Martell Director of Real Estate
257 East Main Street and Counsel
Barrington, Illinois 60010 5660 New Northside Drive
Suite 1400
Atlanta, Georgia 30328
With a copy to: With a copy to:
Gardner, Carton & Douglas First Data Merchant Services
Attention: Glen W. Reed Corporation
321 North Clark Street Attention: Roger L. Pierce, President
Suite 3400 700 Hansen way
Chicago, Illinois 60610-4795 Palo Alto, CA 94303
Any notice shall be deemed to have been given three (3) days after the date
deposited in the United States mail, or on the first business day after sending
when delivery by recognized overnight courier providing proof of delivery, in
the manner aforesaid.
Either party, by written notice to the other, shall have the right to change
the addresses for notice(s) to be sent to such party, and to add or substitute
entities to which a copy of any notice shall be sent by the other party.
29
<PAGE>
27. Brokerage. Landlord and Tenant acknowledge that no real estate broker
brought about this lease transaction. Landlord hereby indemnifies Tenant
against the claims of any party claiming by, through or under Landlord in
connection with this Lease transaction, and Tenant hereby indemnifies Landlord
against the claims of any party claiming by, through or under Tenant in
connection with this Lease transaction.
28. Estoppel. Landlord and Tenant shall, at any time upon not less than
twenty (20) days prior written notice, execute and deliver to a prospective new
landlord, lender, or assignee or subtenant of Tenant, as the case may be, a
statement in writing (i) certifying that this Lease in unmodified and in full
force and effect (or if modified, stating the nature of such modification and
certifying that this Lease, as so modified, is in full force and effect) and the
date to which the rent and other charges are paid in advance, if any, and (ii)
acknowledging that there are not, to the party's knowledge, any uncured defaults
on the part of the other party hereunder, or so specifying such defaults if any
are claimed, and (iii) other reasonable requests that relate to the Lease.
29. Hazardous Substances.
A. For purposes of this Paragraph 29, "Hazardous Substance" means:
(i) "Hazardous Substances" as defined by the Comprehensive
Environmental Response, Compensation and Liability Act ("CERCLA"), 42 U.S.C.
(S)9601 et. seq., as amended, and all regulations promulgated thereunder,
the Federal Clean Air Act, as amended (42 U.S.C. (S)7401 et seq.) and the
Federal Water Pollution Control Act ("FWPCA"), 33 U.S.C. (S)1317 et seq. as
amended and all regulation promulgated thereunder;
(ii) "Hazardous Waste" as defined by the Resource Conservation and
Recovery Act ("RCRA"), 42 U.S.C. (S)6602 et. seq. as amended and all
regulations promulgated thereunder;
(iii) Any pollutant or contaminant or hazardous, dangerous or toxic
chemicals materials or substances within the meaning of any other applicable
federal, state or local law, regulation, ordinance or requirement (including
consent decrees and administrative orders) relating to or imposing liability
or standards of conduct concerning any hazardous, toxic or dangerous waste,
substance or material, all as amended or hereafter amended;
(iv) More than 100 gallons of crude oil which is liquid at standard
conditions of temperature and pressure (80 degrees Fahrenheit and 14.7
pounds per square inch absolute);
(v) Any radioactive material, including any source, special nuclear or
by-product material as defined in 42 U.S.C. (S)2011 et. seq. as amended or
hereafter amended, and all regulations promulgated thereunder;
30
<PAGE>
(vi) Friable asbestos or any asbestos which becomes friable during the
term of this Lease; and
(vii) Anything defined as a hazardous, toxic or radioactive material,
waste or substance or the use, transportation or disposal of which is
regulated under applicable California laws or rules and regulations issued
pursuant thereof;
(all of the foregoing statutes, laws, ordinance, rules, regulations, and common
law theories being sometimes hereinafter collectively referred to as "Envlaws").
B. Landlord and Tenant acknowledge the environment condition of the Land
as described in that certain Site Management Plan prepared by Geomatrix
Consultants dated September 5 , 1996, a copy of which Landlord has provided to
Tenant. Prior to the Construction Completion Date, Landlord shall cause to be
performed all asbestos and soil removal and disposal or other remediation
provided for under and in compliance with Section 4.4.7 of the Sale Agreement,
as well as all additional environmental clean-up of Hazardous Substances as
required by Section 4.4.7 of the Sale Agreement. Landlord shall indemnify,
defend and hold Tenant harmless from all damages, costs, losses, expenses
(including but not limited to reasonable attorney's fees and engineering fees)
arising from any breach by Landlord of the preceding covenant; provided however,
the foregoing indemnification shall terminate upon the expiration of one (1)
year from the Construction Completion Date. Notwithstanding the foregoing, in
no event shall Tenant have the right to terminate this Lease or have any right
of set-off arising out of any breach or claimed breach by Landlord in its
obligations hereunder; it being expressly acknowledged and agreed that the Base
Rent and Additional Rent, and all other charges and sums payable by Tenant
hereunder, shall commence at the times provided herein and shall continue to be
payable as provided under this Lease.
C. Tenant shall not allow any Hazardous Substance to be brought on to the
Demised Premises and shall not conduct or authorize the generation,
transportation, storage, treatment or disposal at the Demised Premises, of any
Hazardous Substance other than in quantities incidental to the conduct of
Tenant's Use and in compliance with Envlaws; provided, however, nothing herein
contained shall permit Tenant to allow any so-called "acutely hazardous",
"ultra-hazardous", "imminently hazardous chemical substance or mixture" or
comparable Hazardous Substance to be located on or about the Demised Premises.
D. If the presence, release, threat of release, placement on or in the
Demised Premises, or the generation, transportation, storage, treatment, or
disposal at the Demised Premises of any hazardous substances as a result of
Tenant's operations at the Demised Premises (i) gives rise to liability
(including, but not limited to, a responses action, remedial action, or removal
action) under Envlaws, (ii) causes a significant public health effect, or (iii)
pollutes or threatens to pollute the environment, Tenant shall promptly take any
and all remedial and removal action necessary to clean up the Demised Premises
and mitigate exposure to liability arising from the hazardous substance, whether
or not required by law.
E. Tenant shall indemnify, defend and hold Landlord harmless from all
damages costs, losses, expenses (including, but not limited to, actual
attorneys', fees and engineering fees) arising from or attributable to the
existence of any hazardous substances at the Demised Premises
31
<PAGE>
as a result of Tenant's operations at the Demised Premises, and (ii) any
breach by Tenant of any of its covenants contained in this Paragraph 29.
F. Upon request by Landlord during the term of this Lease, prior to the
exercise of any Extension Term, Tenant shall undertake and submit to Landlord an
environmental audit from an environmental consulting firm reasonably acceptable
to Landlord which audit shall evidence Tenant's compliance with this Paragraph
29. Tenant shall bear the cost of such environmental audit unless such audit
discloses that Tenant has complied with the provisions of this Paragraph 29 in
which event Landlord shall pay for such audit.
G. Landlord or Tenant shall give the other prompt written notice upon
discovery of any Hazardous Substance at or adjacent to the Demised Premises.
Landlord and Tenant's obligations under this Paragraph 29 shall survive
termination of the Lease.
30. Holdover. Should Tenant continue to occupy the Demised Premises after
expiration of the term or any renewal thereof and provided Landlord has notified
Tenant thirty (30) days prior to the expiration of the term or any renewal term
that Landlord is negotiating or has executed a lease with a third party for the
Demised Premises or any portion thereof, Tenant shall be deemed to be occupying
the Demised Premises without claim or right and Tenant shall pay Landlord all
costs arising out of loss or liability resulting from delay by Tenant in so
surrendering the Demised Premises as above provided and shall pay a charge for
each day of occupancy an amount equal to 150 % the Base Rent (on a per diem
basis) then reserved hereunder. In the event Landlord has failed to notify
Tenant in writing within thirty (3) days prior to the expiration of the term or
any renewal term that Landlord is negotiating or has executed a lease with a
third party or the Demised Premises or any portion thereof, Tenant shall be
entitled to occupy the Demised Premises for a period of sixty (60) days
following expiration of the term for any renewal term on the same terms and
conditions as such term or renewal term (including Base Rental and additional
rental). Should Tenant continue to occupy the Demised Premises following such
sixty (60) day period, Tenant shall be deemed to be occupying the Demised
Premises without claim or right and Tenant shall pay Landlord as a full measure
of all loss or liability resulting from delay b Tenant in so surrendering the
Demised Premises as above provided a charge for each day of occupancy on amount
equal to 200% of the Base Rent and Additional Rent ( on a per diem bases then
reserved hereunder.
31. Surrender.
A. Under any termination or expiration of this Lease, Tenant shall
surrender the Demised Premises in the same condition as existed at the
Commencement Date, except for normal wear and tear and damage caused by the fire
or other casualty; provided, however, that nothing in this Paragraph 31 is
intended to change or diminish Tenant's obligations under any other part of this
Lease. Tenant shall remove the Alterations it is required to remove pursuant to
the terms of Paragraph 8 hereof. Any damage to the Demised Premises resulting
from the removal of such Alterations shall be required by Tenant at Tenant's
expense. If the Demised Premises be no surrendered as above set forth, Tenant
shall indemnify, defend and hold Landlord harmless against loss or liability
resulting from the delay by Tenant in so surrendering the Demised Premises,
including, without limitation any claim made by any succeeding occupant founded
on such delay.
32
<PAGE>
All property of Tenant not removed on or before the last day of the term of
this Lease (subject to Tenant's right to occupy the Demised Premises following
expiration of the term of this Lease as set forth in Paragraph 30 hereof or
within fifteen (15) days thereafter shall be deemed abandoned. Tenant hereby
appoints Landlord its agent t remove all property of Tenant from the Demised
Premises upon termination of this Lease and to cause its transportation and
storage for Tenant's benefit, all at the sole cost and risk of Tenant and
Landlord shall not be liable for damage, theft, misappropriation or loss thereof
and Landlord shall not be liable in any manner in respect thereto. Tenant shall
pay all costs and expenses of such removal transportation and storage. Tenant
shall reimburse Landlord upon demand of or any expenses incurred by Landlord
with respect to removal or storage of abandoned property and with respect to
restoring said Demised Premises to good order, condition and repair.
32. Liens. Landlord shall deliver the Demised Premises to the Tenant free
of all mechanic's and materialmen's liens or bond over all such mechanic's and
materialmen's liens. Tenant has no authority, express or implied to create or
place any lien or encumbrance of any kind or nature whatsoever upon, or in any
manner to bind the interest of Landlord or Tenant in the Demised Premises, or to
charge the rentals payable hereunder for any claim in favor of any person
dealing with Tenant, including those who furnish material or perform labor for
any construction or repairs, and Tenant covenants and agrees that it shall not
mortgage, encumber or pledge this Lease or any interest therein. The preceding
sentence shall not be construed as prohibiting Tenant from making Alterations as
provided in Paragraph 8 above or from permitting any other mechanics or
materialmen's lienable work to be performed as long as such work is not
prohibited by this Lease. Tenant agrees to indemnify and hold Landlord harmless
from any lien filed against the Demised Premises on account of work performed by
or on behalf of Tenant and from any and all losses, costs, damages, expenses,
liabilities, suites, penalties, claims and damages (including reasonable
attorney fees) arising from or relating to such lien. After Tenant's receipt of
notice or actual knowledge of the placing of any lien or encumbrance against the
Demised Premises, Tenant shall immediately give Landlord written notice thereof.
Tenant shall within ten (10) days therefrom remove such lien by payment or bond.
If Tenant shall fail to discharge such mechanic's lien within such period,
then, in addition to any other right or remedy of Landlord, Landlord may, but
shall not be obligated to, discharge the same by paying to the claimant the
amount claimed to be due by procuring the discharge of such lien as to the
Demised Premises by deposit in the court having jurisdiction of such lien, a
cash sum sufficient to secure the discharge of the same, or by the deposit of a
bond or other security with such court sufficient in form, content and amount to
procure the discharge of such lien, or in such other manner as is now or may in
the future be provide by present or future law for the discharge of such lien as
a lien against the Demised Premises. Any amount paid by Landlord, or the value
of any deposit so made by Landlord, together with all costs, fees and expenses
in connection therewith (including reasonable attorneys' fees of Landlord),
together with interest thereon at the rate se forth in Paragraph 33 hereof,
shall be repaid by Tenant to Landlord on demand by Landlord and if unpaid my be
treated as Additional Rent.
All materialmen, contractors, artisans, mechanics, laborers and any other
person now or hereafter furnishing any labor, services, material, supplies or
equipment to Tenant with respect to the Demised Premises, or any portion
thereof, are hereby charged with notice that they must
33
<PAGE>
look exclusively to Tenant to obtain payment for the same. Notice is hereby
given that Landlord shall; not be liable for any labor, services, materials,
supplies, skill, machinery, fixtures or equipment furnished or to be furnished
to Tenant upon credit, and that no mechanic's lien or other lien for any such
labor, services, materials, supplies, machinery, fixtures or equipment shall
attach to or affect the estate or interest of Landlord in and to the Demised
Premises, or any portion thereof.
33. Interest; Late Charge. Base Rent payable pursuant to Paragraph 3
hereof by Tenant to Landlord under this Lease, if not paid when due, and any
other charges payable by Tenant hereunder not paid when due, including any
charges, expenses, liabilities or fees in connection with a default by Tenant,
shall accrue interest at the rate of prime (as announced from time to time by
the First National Bank of Chicago) plus one percent (1%) per annum from the due
date until paid, said interest to be in addition to Base Rent and other charges
under this Lease and to be paid to Landlord by Tenant upon demand. In addition,
if any installment of Base Rent and other charges payable pursuant to this
Lease by Tenant to Landlord is not paid within five (5) days after receipt by
Tenant of a written notice thereof from Landlord, Tenant shall pay Landlord a
late charge in an amount equal to two percent (2%) of the amount then due to
defray the increased cost of collecting late payments.
34. Inspections. Landlord, its agents or employees may, after providing
Tenant with at least twenty-four (24) hours prior notice except in an emergency
situation, to (a) exhibit the Demised Premises to prospective purchasers or
lenders; (b) inspect the Demised Premises to see that Tenant is complying with
its obligations hereunder; and (c) exhibit the Demised Premises during the last
six (6) months of the term to prospective tenants; provided that Landlord shall
comply at all times with Tenant's reasonable security requirements.
35. Transfer of Landlord's Interest. Tenant acknowledges that Landlord has
the right to transfer its interest in the Demised Premises and in this Lease at
any time after the date which is eighteen (18) months after the Commencement
Date and subject to the provisions of Paragraph 52 hereof, and Tenant agrees
that in the event of any such transfer Landlord shall automatically be released
from all liability under this Lease except of any liabilities accruing prior to
the date of transfer for which Tenant has identified in an estoppel certificate
or by written notice to Landlord, and Tenant agrees to look solely to such
transferee for the performance of Landlord's obligations hereunder; provided,
however, any such transferee shall be deemed to have assumed the obligations of
Landlord hereunder subject to the conditions and limitations herein contained.
Tenant agrees to look solely to Landlord's interest in the Demised Premises for
the recovery of any judgment from Landlord, it being agreed that Landlord, or if
Landlord is a partnership, its partners whether general or limited, or if
Landlord is a corporation, its directors, officers or shareholders, or if
Landlord is a limited liability company, its members or manners, shall never be
personally liable for such judgement. Without limiting the generality of the
foregoing, Tenant agrees that Landlord may transfer its interest in this Lease
to any entity controlled by, controlling or under common control with Landlord,
that acquires the Demised Premises and from and after such transfer Landlord
shall be released from liability, as aforesaid.
34
<PAGE>
36. Indemnity. (a) To the fullest extent allowed by law, Tenant shall at
all times Indemnify, defend and hold Landlord harmless against and from any and
all claims by or on behalf of any person or persons, firm or firms, corporation
or corporations, arising from the conduct or management, or from any work or
things whatsoever done in or about the Demised Premises, and will further
indemnify, defend and hold Landlord harmless against and from any and all claims
arising during the term of this Lease, or arising from any breach or default on
the part of Tenant in the performance of any covenant or agreement on the part
of Tenant to be performed, pursuant to the terms of this Lease, or arising from,
any act or negligence of Tenant, its agents, servants, employees or licensees,
or arising from any accident, injury or damage whatsoever caused to any person,
firm or corporation occurring during the term of this Lease, in or about the
Demised Premises or upon the sidewalk and the land adjacent thereto, and from
and against all costs, attorneys' fees, expenses and liabilities incurred in or
about any such claim or action or proceeding by counsel reasonably satisfactory
to Landlord. Tenant's obligations under this Paragraph 36 shall be insured by
contractual liability endorsement on Tenant's policies of insurance required
under the provision of Paragraph 17 hereof.
(b) Landlord shall protect, indemnify and hold Tenant harmless from
and against any and all loss, claims, liability or costs (including court
costs and attorneys' fees) incurred by reason of: (a) any damage to any
property or any injury (including but not limited to death) to any person
occurring in, or on or about the Demised Premises or the Building to the
extent that such injury or damage shall be proximately caused by the
Landlord's affirmative acts of negligence or willful misconduct of Landlord
or its agents, servants or employees; provided, however, that such
indemnification shall be limited to the extent of the sum of: (i) amounts
of insurance proceeds recovered by Landlord under insurance policies
carried by Landlord for such injury or damage, after deductibles, or
insurance process that would have been received in the event Landlord had
not elected to self-insure, and (ii) the deductible amounts for such claims
under such insurance policies. The provisions of this Article shall survive
the termination of the Lease with respect to any claims or liability
occurring prior to such termination.
(c) Notwithstanding the foregoing indemnification obligations,
Landlord and Tenant both hereby release the other and the other's officers
directors, partners, employees and agents from any claim with the
indemnified party might have to the extent that the cost of any such claim
is reimbursed by insurance proceeds recovered by the releasing party, and
both landlord and Tenant shall confirm that their insurance providers shall
similarly waive all such claims.
37. Modification of Lease. The terms, covenants and conditions of this
Lease may not be changed orally but only by an instrument in writing signed by
the party against whom enforcement of the change is sought. The failure of
either party hereto to insist in any one or more cases upon the strict
performance of any term, covenant or condition of this Lease to be
35
<PAGE>
performed or observed by the other party hereto shall not constitute a waiver of
relinquishment for the future of any such term, covenant or condition.
38. Memorandum of Lease. Neither party shall record this Lease or any of
the exhibits and/or riders attached hereto, but shall enter into a "short form"
or Memorandum of Lease in recordable form attached hereto as Exhibit F and made
a part hereof, which shall set forth the parties, the legal description of the
land, a description of the Demised Premises, the Commencement Date and
Expiration Date of the term of the Lease, and any options to renew, options to
purchase or rights of first refusal granted hereunder.
39. Paragraph Captions. Paragraph captions herein are for Landlord's and
Tenant's convenience only, and neither limit no amplify the provisions of this
Lease.
40. Entire Agreement. This Lease represents the entire agreement between
Landlord and Tenant and supersedes all prior agreements, both written and oral.
The terms, covenants and conditions of this Lease shall be binding upon and
shall inure to the benefit of Landlord and Tenant and therein respective
executors, administrators, heirs, distributees, legal representatives successors
and assignees.
41. Choice of Law and Interpretation. This Lease shall be governed by the
internal law of the State in which the Demised Premises is situated, without
considering such state's choice of law rules. Should any provision of this
Lease require judicial interpretation, it is agreed that the court interpreting
or construing the same shall not apply a presumption that the terms of any such
provision shall be more strictly construed against one party or the other by
reason of the rule of construction that a document is to be construed most
strictly against the party who itself or through its agent prepared the same, it
being agreed that the agents of all parties hereto have participated in the
preparation of this Lease.
42. Prevailing Party. If either party hereto files a lawsuit against the
other party relating to performance or non-performance under this Lease, and the
court has entered a judgment in favor of one party on one or more counts and no
judgment in favor of the other party on any counts, then the non-prevailing
party shall pay the prevailing party's reasonable attorney's fees and costs in
connection with the lawsuit.
43. Exhibits. Attached hereto and made a par thereof are the following:
Exhibit A - Legal Description
Exhibit B - Site Plan
Exhibit C - Plans
Exhibit C-1 Construction Schedule
Exhibit D - Schedule of Rents
Exhibit E - Lease Term Agreement
Exhibit F - Memorandum of Lease
Exhibit G - Landlord's Development Costs
Exhibit H - Permitted Exceptions
Exhibit I - Escrow Agreement
36
<PAGE>
44. Guarantee. All obligations on the part of Tenant to be paid, performed
and complied with are unconditionally guaranteed by First Data Corporation (the
"Guarantor") according to the provisions of the Guarantee executed by Guarantor
in a form prepared by Landlord.
45. Independent Covenants. It is the express intent of Landlord and
Tenant that (a) the obligations of Landlord and Tenant hereunder shall be
separate and independent covenants and agreements and that the Base Rent and
Additional Rent, and all other charges and sums payable by Tenant hereunder,
shall commence at the times provided herein and shall continue to be payable in
all events; (b) all cost or expenses of whatsoever character or kind, general or
special, ordinary or extraordinary, foreseen or unforeseen, and of ever kind and
nature whatsoever that may be necessary or required in and about the Demised
Premises, or any portion thereof, and Tenant's possession or authorized use
thereof during the term of this Lease, shall be paid by Tenant and all
provisions of this Lease are to be interpreted and construed in light of the
intention expressed in this Paragraph 45; (c) the Base Rent specified in
Paragraph 3 shall be absolutely net to Landlord so that this Lease shall yield
net to Landlord the Base Rent specified in Paragraph 3 in each year during the
term of this Lease (unless extended or renewed at a different Base Rent; (d) all
Impositions, insurance premiums, utility expenses, repair and maintenance
expenses, and all other costs, fees, interest, charges, expenses, reimbursements
and obligations of every kind and nature whatsoever relating to the Demised
Premises, or any portion thereof, which may arise or become due during the term
of this Lease, or any extension or renewal thereof, shall be paid or discharged
by Tenant as Additional Rent.
46. Entry by Landlord. Subject to the provisions of Section 34 hereof,
Tenant agrees to permit Landlord or Landlord's mortgagee and authorized
representative of Landlord or Landlord's mortgagee to enter upon the Demised
Premises at all reasonable times during ordinary business hours for the purpose
of inspecting the same and making any necessary repairs to comply with any laws,
ordinances, rules, regulations or requirements of any public body, or the Board
of Fire Underwriters, or any similar body; provided that Landlord shall comply
at all times with Tenant's reasonable security requirements. Nothing herein
contained shall imply any duty upon the part of Landlord to do any such work
which, under any provision of this Lease, Tenant may be required to perform and
the performance thereof by Landlord shall not constitute a waiver of Tenant's
default in failing to perform the same. Landlord may, during the progress of
any work, keep and store upon the Demised Premises all necessary material, tools
and equipment. Landlord shall not in any event be liable for inconvenience,
annoyance, disturbance, loss of business or other damage to Tenant by reason of
making repairs or the performance of any work in or about the Demised Premises,
or on account of bringing material, supplies and equipment into, upon or through
the Demised Premises during the course thereof, and the obligations of Tenant
under this Lease shall not be thereby affected in any manner whatsoever;
provided, however, Landlord shall use all reasonable efforts to conduct any
entry into the Demised Premises so as to interfere with the Business of Tenant
as little as reasonably practical under the circumstances.
47. [Deleted by intent of parties.]
48. Survival of Obligations. Except as otherwise provided herein to the
contrary, all obligations of Tenant hereunder not fully performed as of the
expiration or earlier termination of
37
<PAGE>
the term of this Lease shall survive the expiration of earlier termination of
the term hereof for a period of one (1) YEAR.
49. Lease Subject to Landlord's Acquisition of Demised Premises. Anything
herein to the contrary notwithstanding, it is agreed and acknowledged by the
parties hereto that as of the date hereof, Landlord does not own the Demised
Premises. Therefore, anteing herein to the contrary notwithstanding, the
rights, duties and obligations of Landlord and Tenant hereunder are expressly
subject to and contingent upon acquisition by Landlord of the Demised Premises
by December 31 , 1997 ("Contingency Date"), upon terms and conditions
acceptable to Landlord, in its sole and absolute discretion, including, without
limitation, procuring project financing on terms and conditions acceptable to
Landlord. In the event Landlord has not acquired the Demised Premises by the
Contingency Date on term and conditions acceptable to Landlord, as aforesaid,
Landlord shall notify Tenant, and either party may terminate this Lease at any
time thereafter (but prior to the date Landlord acquires the Demised Premises)
by delivering written notice of such termination to the other party, whereupon
the parties shall be released and discharged from any and all obligations and
liabilities not therefore accrued under this Lease provided, however, in the
event the Lease is so terminated, Tenant shall pay to Landlord, within ten (10)
days from the date Landlord has submitted a written statement to Tenant
requesting such payment, all amounts incurred by Landlord has submitted a
written statement to Tenant requesting such payment all amounts incurred by
Landlord in connection with the proposed acquisition and development of the
Land, including, without limitation, any earnest money deposit, any costs for
required off-site improvements, including sewer and road improvements, all
architectural, engineering, environmental, land planning and other consulting
fees, all title and survey expenses, all costs associated with the proposed
subdivision of Land, any and all fees and expenses associated with procuring
construction and/or other financing for the project, any other costs or expenses
that would not have been incurred by Landlord had Landlord not been involved in
the acquisition and proposed development of the Land and all attorneys, fees
associated with any of the foregoing. Landlord agrees to use all reasonable
efforts to acquire the Demised Premises on terms and conditions acceptable to
Landlord, as aforesaid.
50. Americans With Disabilities Act.
A. In the event that any alteration or repair to the Demised Premises is
undertaken by Tenant with or without Landlord's consent, or is undertaken by
Landlord at Tenant's request during the term of this Lease (including any
renewal or extension thereof) such alteration or repair (i) shall be designed
and constructed in full compliance with the Americans With Disabilities Act, as
amended from time to time (the "Act") if such alteration or repair is undertaken
by Tenant, and (II) shall be designed by Tenant in full compliance with the Act
in such alteration or repair is undertaken by Landlord at Tenant's request, and
the cost of any such design, alteration or repair to the Demised Premises shall
be borne by Tenant, including without limitation (a) the cost of any such
design, alteration or repair required as a result of (i) Tenant or an assignee
or subtenant being deemed a "Public Accommodation" or the Demised Premises being
deemed a "Place of Public Accommodation" or (ii) such alteration or repair being
deemed to affect an "Area of Primary Function" (as such terms are defined in the
Act); and (b) the cost of the installation or implementation of any "Auxiliary
Aid" required under the Act as a result of the operation of any business within
the Demised Premises. In addition, Tenant shall be responsible for all costs
and expenses incurred or to be incurred in order to cause the Demised Premises
and the operation of any business within the Demised Premises to comply with the
Act, and, if
38
<PAGE>
Tenant fails to keep and maintain the Demised Premises in compliance with the
Act, Landlord shall have the right but not the obligation, at Tenant's sole
cost and expense, to enter the Demised Premises and cause the Demised Premises
to be put into compliance with the Act; and Tenant shall indemnify, defend and
hold Landlord harmless from and against any and all costs, claims and
liabilities, including without limitation, attorneys' fees arising from or
related to Tenant's failure to maintain and keep the Demised Premises in
compliance with the Act.
B. In connection with its construction of the Landlord's Improvements
pursuant to Paragraph 4 hereof, Landlord represents and warrants that the
Landlord's Improvements to be constructed in accordance with the Plans will
comply in all material respects with all applicable laws, including without
limitation, the Act, and Landlord covenants that the Demised Premises delivered
to Tenant as of the Construction Completion Date shall comply in all material
respects with all applicable laws, including without limitation, the Act.
Landlord shall indemnify, defend and hold Tenant harmless from all damages,
costs, losses, expenses (including but not limited to reasonable attorneys'
fees) arising from any breach by Landlord of the preceding covenant; provided
however the foregoing indemnification shall terminate upon the expiration of one
(1) year from the Construction Completion Date. Notwithstanding the foregoing,
in no event shall Tenant have the right to terminate this Lease or have any
right of set-off arising out of any breach or claimed breach by Landlord in its
obligations hereunder; it being expressly acknowledged and agreed that the Base
Rent and Additional Rent, and all other charges and sums payable by Tenant
hereunder, shall commence at the times provided herein and shall continue to be
payable as provided herein.
51. Reports by Tenant. Upon request by Landlord at any item after 135
days after the end of the applicable fiscal year of Tenant, Tenant shall deliver
to Landlord (within 15 days after receipt of written request) a copy of the
audited financial statement of any guarantor of Tenant's obligations under this
Lease. If such audited statements are not available, Tenant may provide such
statements certified by such guarantor's chief financial officer as being true
and correct, in accordance with generally accepted principals of accounting
consistently applied over the applicable periods. Said financial statements
shall only be required in connection with a proposed sale or mortgaging of the
Demised Premises and shall be held in confidence by Landlord and any such
proposed purchases or lender or their respective successors or assigns.
Notwithstanding the foregoing, Tenant shall cause First Data Corporation to
submit annual audited financial statements to Landlord and Landlord's mortgagee
in the manner set forth herein if First Data Corporation ceases to be a publicly
traded company.
52. Option to Purchase. Subject to the provisions hereinafter set forth,
and provided that Tenant is not then in default hereunder, Landlord hereby
grants to Tenant the option to purchase the Demised Premises upon the following
terms and conditions:
A. Landlord shall notify Tenant thirty (30) days prior to the date that it
intends to make the Demised Premises available for sale to third parties.
Included with such notice shall be the proposes purchase price for the Demised
Premises,, as well s any other relevant economic terms being offered by
Landlord. In no event shall Landlord have the right to convey the Demised
Premises or otherwise make the Demised Premises available for sale to third
parties until eighteen (18) months after the Commencement Date.
39
<PAGE>
B. If, at any time after notice is delivered to Tenant as set forth
above, Landlord enters into a serious negotiation with a prospective purchaser
to purchase the Demised Premises, then Landlord shall notify Tenant in writing
of (i) the fact of such negotiation, (ii) the purchase price agreed to between
Landlord and such prospective purchaser, and (iii) the other relevant agreed
upon economic terms upon which such purchaser would acquire the Demised
Premises, and Tenant must within ten (10) business days thereafter, by written
notice to Landlord, elect to exercise the option to purchase the Demised
Premises upon all of the same terms and conditions as are contained in
Landlord's notice to Tenant in which event the parties shall enter into a
definitive agreement incorporation said terms and conditions. If Tenant does
not elect to purchase, Landlord shall have the right to sell to a third party
on the same terms and conditions provided to Tenant or shall submit any
modified terms to Tenant in accordance with the above. In no event shall
Tenant be afforded more than three (3) opportunities to exercise its option
hereunder, in connection with more than three (3) different offers from three
(3) different third parties.
C. If Tenant exercises its option to purchase hereunder, the closing of
such purchase shall occur on the date set forth in the definitive agreement
entered into between Landlord and Tenant. At the closing, Tenant shall pay the
purchase price via cash or wire transfer of immediately available funds to
Landlord, and Landlord shall deliver to Tenant a general warranty deed (or
equivalent) to the Demised Premises conveying good and marketable fee simple
title in Tenant to the Demised Premises, subject to no liens, encumbrances or
other exceptions to title other than the Permitted Exceptions and taxes for the
current year, and any exceptions to title that have been caused by Tenant or
that Tenant has accepted in writing ( other than any mortgages or other liens,
which must be discharged by Landlord at or prior to such closing). On the
closing date, Landlord and Tenant shall also execute and deliver such other
documents and instruments as are customary in similar transactions and/or
reasonably necessary to implement the terms and conditions of this Lease, and to
allow Tenant to obtain an extended coverage ALTA owner's title policy insuring
Tenant's fee simple ownership of the Demised Premises in accordance with the
above.
D. Landlord covenants and agrees that if any exceptions to title other
than the Permitted Exceptions shall be revealed by the deed or title policy,
Landlord will at its sole cost and expense clear the title of such exceptions as
soon as reasonably practical but, in any event, within six (6) months after the
intended closing date (unless Tenant shall in writing extend such period), and
the actual closing (including the payment of the purchase price) of such
purchase of the Demised Premises shall be delayed until the title thereto has
been cleared. Until such time as Tenant's purchase of the Demised Premises is
closed as hereinabove provided, Tenant shall continue to occupy and possess the
Demised Premises under the terms and conditions of this Lease. If for any
reason such purchase is not closed, this Lease shall continue in full force and
effect as if Tenant had not exercised the aforesaid option to purchase, and
Tenant shall be entitled to retroactively exercise any option for any Extension
Term to the extent the normal option election date occurred after Tenant
exercised its option to purchase the Demised Premises.
E. Upon Tenant`s notice to Landlord of the exercise of Tenant's option to
purchase, Landlord shall provide Tenant with copies of all surveys, title
insurance policies, title instruments and other such documents in Landlord's
possession pertaining to the Demised Premises. Tenant shall pay for the cost of
the title insurance policy, the cost to prepare any
40
<PAGE>
survey required by Tenant and the cost of any escrow or closing services, and
any cost or expense in connection with any endorsements to the title policy
requested by Tenant. Landlord shall be responsible for the cost of compliance
with any subdivision, lot split or similar regulations which are applicable to
or in connection with the conveyance of the Demised Premises to Tenant. All
rents shall be pro-rated between the parties as of the date of closing. Tenant
shall pay the cost of any documentary stamp taxes required for recording the
deed, as well as any transfer taxes. Any other maters at closing not
specifically provided for herein shall be handled and the cost hereof charged
to one or the other or both of the parties as shall be the ordinary custom and
practice for the handling of such matters or the apportioning of the cost
hereof then prevalent in the City of Sunnyvale, Santa Clara County,
California.
F. The option hereunder may only be exercised by Tenant or a subsidiary,
affiliate or related entity of Tenant. If neither Tenant or a subsidiary,
affiliate or related entity is then occupying all or a portion of the Demised
Premises, Tenant shall have no rights hereunder.
53. No Third Party Beneficiaries. The obligations of Tenant set forth
hereunder (including, without limitation, the obligations set forth in Sections
5A, 7A, 11B and 50), are covenants from Tenant to Landlord only and do not
create any third party beneficiaries of such obligations.
54. Counterparts. This Lease may be executed in counterparts, each of
which shall be deemed an original but all of which together shall constitute but
one and the same instrument.
55. Consents and Approvals. Landlord and Tenant agree that any consents
or approvals to be provided by either party will not be unreasonably withheld or
delayed unless specifically provided otherwise herein.
56. Limitation on Damages. In no event shall Landlord or Tenant be liable
under any theory of tort, contract, strict liability or other legal or equitable
theory for any punitive, special, incidental, indirect or consequential damages,
each of which is hereby excluded by agreement of the parties regardless of
whether or not any party has been advised of the possibility of such damages.
57. Tenant's Property. All fixtures, equipment, improvements and
appurtenances attached to, or built into, the Demised Premises that are
installed by Tenant at Tenant's expense shall be Tenant's property until the
termination of this Lease. All of the foregoing items installed at Tenant's
expense as well as all paneling, partitions and business and trade fixtures and
communication and office equipment which are installed in the Demised Premises
by Tenant, and all furniture, furnishing and other articles of movable personal
property owned by Tenant and located in the Demised Premises or the Building
(all of which are hereinafter referred to as "Tenant's Property") shall belong
to TENANT, may be removed by Tenant at any time during the term hereof, and may
be removed by Tenant at the end of the term hereof or within fifteen (15) days
thereafter, whether as a result of the normal expiration of the term of this
Lease or of the early termination of this Lease pursuant to the terms hereof (as
a result of Tenant's default hereunder or otherwise). Tenant shall repair any
damage resulting from the removal of Tenant's Property and leave the Demised
Premises in a commercially reasonable condition. Any items of
41
<PAGE>
Tenant's Property not so removed shall, if not required to be so removed by
Tenant pursuant to Paragraph 8 hereof, be deemed abandoned and retained by
Landlord as its property thereafter.
Landlord waives any landlord or other lien it may have on Tenant's Property
and shall not seek to enforce same, whether upon Tenant's default or otherwise.
42
<PAGE>
IN WITNESS WHEREOF, Landlord and Tenant have duly executed this Lease as
of the day and year first above written.
LANDLORD:
SUNNYVALE PARTNERS LIMITED
PARTNERSHIP, an Illinois limited partnership
By: Ridge Sunnyvale, Inc.
Its: General Partner
By: /s/ James Small
-------------------------------
Its: President
-------------------------------
TENANT:
FIRST DATA MERCHANT SERVICES
CORPORATION, a Florida corporation
By: /s/ David Schlapbach
-----------------------------------
Its: Assistant Secretary
-----------------------------------
<PAGE>
XXX
Legal Description
-----------------
Real Property in the City of Sunnyvale, County of Santa Clara, State of
California described as follows:
Beginning at the Southeasterly corner of that certain 5.58 acre parcel of land
described in the Deed to Stauffer Chemical Company, a California Corporation as
said Deed is filed for record in Book 1331 Official Records, Page 256 in the
Office of the Recorder of said County said Point of Beginning being in the
centerline of Fremont Avenue;
Thence from said Point of Beginning, south 89 degrees 48' West along said
centerline of Fremont Avenue 409.86 feet to the Easterly line of the land
described in the Deed to said Stauffer Chemical Company, filed for record in
Book 2891 Official Records, Page 325 in the Office of the Recorder of Said
County;
Thence continuing South 89 degrees 48' West along said centerline 143.22 feet to
the centerline of Stevens Creek as shown on the Map of the I.J. Truman
Subdivision No. 2 filed for record October 3, 1904 in Vol. "F-3" of Maps, Page
99 in the Office of the Recorder of said County last said point being also the
Southwesterly corner of Lot 24 of said subdivision;
Thence leaving Fremont Avenue and running along the centerline of Stevens Creek
and the Westerly boundary of Lot 24 as shown on said Subdivision Map the
following courses:
North 50 degrees West 46.20 feet; thence North 15 degrees 45' West (North 16
degrees 45' West Truman Sub.) 118.80 feet; thence North 1 degree East 135.30
feet; thence North 37 degrees 30' East 264.00 feet; thence North 74 degrees East
178.20 feet; thence North 35 degrees 15' East 126.72 feet; thence North 23
degrees 30' East 96.66 feet; thence North 61 degrees 45' East to the point of
intersection of said centerline of Stevens Creek with the Northerly prolongation
of the Easterly line of said 5.58 acre parcel; thence South 0 degrees 01' West
leaving said boundary of Lot 24, along said prolongation and Easterly line,
823.39 feet to the Point of Beginning.
Excepting therefrom the lands described in the Deed from said Stauffer Chemical
Company to the State of California recorded in Book 5541 Official Records, Page
263 in the Office of the Recorder of said County:
Commencing at the Southeasterly corner of that certain 5.58 acre parcel of land
conveyed to Stauffer Chemical Company, a Corporation, by Deed recorded February
16, 1946 in Book 1331 at Page 256, official Records of Santa Clara County;
Thence along the Easterly line of said parcel and the Northerly prolongation
thereof North 1 degree 00' 41" East 823.39 feet to the general Westerly line of
the parcel of land conveyed to Stauffer Chemical Company, a Corporation, by Deed
recorded June 10, 1954 in Book 2891 at Page 325, Official Records of Santa Clara
County; thence along last said line South 62 degrees 40' 37" West, 197.03 feet
to a line parallel with and distant 48.00 feet Westerly, at right angles, from
<PAGE>
the "ME" line of the Department of Public Works' Survey for the State Freeway
in Santa Clara County, Road V-SC1-114-A; thence along said parallel line South
16 degrees 01' 13" East, 479.62 feet; thence, South 9 degrees 06' 48" East,
167.07 feet; thence along a tangent curve to the right with a radius of 40.00
feet, through an angle of 99 degrees 50' 37", an arc length of 69.70 feet to a
line parallel with and distant 60.00 feet, Northerly, at right angles, from
the centerline of Fremont Avenue (60.00 feet wide); thence along last said
parallel line, North 89 degrees 16; 11: West, 115.00 feet; thence south 76
degrees 50' 32" West, 124.99 feet; thence South 0 degrees 43' 49" West 30.00
feet to said centerline; thence along last said line South 89 degrees 16' 11"
East 278.00 feet to the point of commencement.
2
<PAGE>
EXHIBIT B
THE PREMISES
------------
18
<PAGE>
EXHIBIT B
SUBLEASE
BY AND BETWEEN
FIRST DATA MERCHANT SERVICES CORPORATION,
A SUBSIDIARY OF FIRST DATA CORPORATION
SUBLESSOR
AND
SOFTWARE.NET CORPORATION
SUBTENANT
<PAGE>
EXHIBIT B
TABLE OF CONTENTS
Incorporation of Recitals........................................... 1
Demise and Term..................................................... 1
Subtenant Improvements Allowance.................................... 2
Subtenant Alterations............................................... 3
Use................................................................. 3
Subordinate to Main Lease........................................... 4
Compliance with Main Lease.......................................... 4
Performance by Sublessor............................................ 5
No Breach of Main Lease............................................. 5
No Privity of Estate................................................ 5
Indemnity........................................................... 5
Rent................................................................ 6
Condition of Premises............................................... 7
Consents and Approvals.............................................. 7
Notice.............................................................. 7
Termination of Main Lease........................................... 8
i
<PAGE>
EXHIBIT B
Maintenance and Repair.............................................. 8
Assignment and Sublettings.......................................... 8
Insurance........................................................... 9
Right to Cure Subtenant's Defaults and Damages...................... 9
Remedies of Sublessor............................................... 10
Brokerage........................................................... 11
Waiver of Jury Trial and Right to Counterclaim...................... 11
No Waiver........................................................... 11
Complete Agreement.................................................. 11
Successors and Assigns.............................................. 11
Interpretation...................................................... 12
Consent of Landlord Under Main Lease................................ 12
Holding Over........................................................ 12
Security Deposit.................................................... 12
Counterparts........................................................ 13
No Offer............................................................ 13
Hazardous Materials................................................. 13
ii
<PAGE>
EXHIBIT B
Signage.............................................................. 13
Parking.............................................................. 14
iii
<PAGE>
SUBLEASE
--------
THIS SUBLEASE ("Sublease") is made and dated as of the ___ day of, _______
1998, by and between FIRST DATA MERCHANT SERVICES CORPORATION, a Florida
corporation, having an address of 5660 New Northside Drive, Suite 1400, Atlanta,
Georgia 30328 ("Sublessor") and SOFTWARE.NET CORPORATION, a California
corporation having an address of 1195 West Fremont Avenue, Sunnyvale, California
("Subtenant").
WITNESSETH:
-----------
WHEREAS, Sublessor is tenant under that certain Build-To-Suit Lease
Agreement dated as of March 18, 1997 (the "Main Lease") with Sunnyvale Partners
Limited Partnership, an Illinois limited partnership ("Overlandlord") as
landlord, whereby Overlandlord leased to Sublessor land and improvements
consisting of a to-be constructed two-story office building containing
approximately 75,197 rentable square feet of office space located at 1195 West
Fremont Avenue, Sunnyvale; California (the "Building");
WHEREAS, the Building has since been constructed; and
WHEREAS, Sublessor desires to sublet a portion of the Building comprised of
approximately 52,185 rentable square feet located on the first and second floors
of the Building as more particularly shown and described on Exhibit B attached
hereto and incorporated herein by this reference (the "Premises") to Subtenant,
and Subtenant desires to sublet the Premises from Sublessor,
WHEREAS, the parties are agreeable to entering into a sublease of the
Premises on the terms and conditions set forth below; and
WHEREAS, unless otherwise defined in this Sublease, all capitalized terms
used herein have the meanings set out for them in the Main Lease.
AGREEMENT
---------
NOW, THEREFORE, for and in consideration of the mutual promises set forth
herein and other good and valuable consideration, the receipt and sufficiency of
which are hereby, acknowledged, Sublessor and Subtenant hereby agree as follows:
1. Incorporation of Recitals. The foregoing recitals are incorporated
into and made a part of this Sublease as if each were specifically recited
herein.
2. Demise and Term. Sublessor hereby subleases the Premises to
Subtenant, and Subtenant hereby hires and accepts the Premises from Sublessor.
The Premises shall include the non-exclusive appurtenant right to the use, in
common with others, of the lobbies, entrances, stairs, corridors, elevators and
other public portions of the Building. The term of this Sublease (the "Term")
shall be the period commencing July 1, 1998 (the "Commencement Date"), and
ending at 12:01 a.m. on the date which is sixty-two (62) months after the
Commencement Date (the "Expiration Date"), unless sooner terminated as herein
provided. Subtenant shall have no option to renew or extend the term of this
Sublease or to expand the Premises.
<PAGE>
3. Subtenant Improvements and Allowance. Sublessor agrees to
contribute a maximum amount of One Dollar and no/100 ($1.00) per square foot of
rentable area of the Premises for the completion of the Subtenant Improvements
(as hereinafter defined) ("Allowance") as more specifically set forth in this
Section 3.
a. Subtenant Improvements shall mean such items of general
applicability to office space that Subtenant desires to be installed in the
interior of the Premises. Subtenant shall deliver to Sublessor a space plan for
the Premises (the "Space Plan"), which Space Plan shall be subject to the
approval of Sublessor, which approval shall not be unreasonably withheld. Upon
Sublessor's approval of the Space Plan, Subtenant shall engage and pay for the
services of a licensed architect to prepare complete and detailed working
drawings and specifications for the construction of the Subtenant Improvements,
showing thereon all Subtenant Improvements (the "Drawings"). The Drawings shall
be subject to the approval of Sublessor, which approval shall not be
unreasonably withheld. If Sublessor should disapprove such Drawings, Sublessor
shall specify to Subtenant the reasons for its disapproval and Subtenant shall
cause the same to be revised to meet the Sublessor and Subtenant's mutual
reasonable satisfaction and Subtenant shall resubmit the same to Sublessor, as
so revised. It is understood by the parties that Subtenant has elected to retain
a general contractor and arrange for the construction and installation of the
Subtenant Improvements itself in a good and workmanlike manner [ by labor union
contractors and subcontractors?] (the "Work"). Subtenant shall submit to
Sublessor the name of the general contractor and major subcontractors for
Sublessor's approval, which shall not be unreasonably withheld, or, at
Sublessor's option, Subtenant shall select its general contractor and major
subcontractors from a list pre-approved by Sublessor. If Sublessor shall reject
the general contractor or any major subcontractor, Sublessor shall advise
Subtenant of the reasons in writing and Subtenant shall choose another
contractor. Along with Subtenant's notice of its general contractor and major
subcontractors, Subtenant shall notify Sublessor of it estimate of the total
costs of the Work and, at Sublessor's option, Subtenant must provide to
Sublessor adequate assurance that Subtenant has the financial resources to pay
for such costs. Subtenant's contractors shall be duly licensed and shall obtain
and provide to Sublessor with certificates evidencing worker's compensation,
public liability and property damage insurance in amounts and forms and with
companies satisfactory to Sublessor. Subtenant's agreement with its contractors
shall require such contractors to provide daily cleanup of the work area to the
extent such clean up is necessitated by the Work, and to take reasonable steps
to minimize interference with other tenants' use and occupancy of the Building.
Subtenant and Subtenant's contractors shall comply with any other reasonable
rules, regulations or requirements that Sublessor or Overlandlord shall impose.
Subtenant may request reasonable changes in the Drawings provided that no change
shall be made to the Drawings without Sublessor's prior written approval, which
shall not be unreasonably withheld or delayed; (b) no such request shall effect
any structural change in the Building or otherwise render the Premises or
Building in violation of applicable laws; (c) Subtenant shall be responsible for
all costs of same; and (d) such requests shall constitute agreement by Subtenant
to any delay in completion caused by Sublessor's reviewing and processing such
change. Subtenant shall promptly pay any and all costs and expenses in
connection with or arising out of the performance of the Work and shall furnish
to Sublessor evidence of such payment upon request. Subtenant agrees not to
suffer or permit any mechanic, materialman, architect, broker or other lien to
be placed or filed against the Premises or the Building. In case any such lien
shall be filed, Subtenant shall immediately file and release such lien of
record. If Subtenant shall fail to have such lien immediately satisfied and
released, Sublessor may, on Subtenant's behalf, without being responsible for
any investigation as to the validity of such lien and without limiting any other
remedies Sublessor may have, pay the same and Subtenant shall upon demand pay
Sublessor the amount so paid.
2
<PAGE>
b. Upon completion of the Work, Subtenant may submit to Sublessor
a request in writing for the Allowance which request shall include: (i) as-built
drawings showing all of the Subtenant Improvements; (ii) a detailed breakdown of
final and total costs, together with receipted invoices showing payment thereof;
(iii) a certified written statement from the architect that the Subtenant
Improvements have been completed in compliance with the Drawings; (iv) final
lien waivers and releases from the architect, general contractor and all
subcontractors and suppliers; and (iv) a copy of a certificate of occupancy for
the Premises. Provided the request includes all of the foregoing, Sublessor
shall pay the Allowance to Subtenant within 30 days of Sublessor's receipt of
such request and all supporting documentation.
c. Subtenant hereby acknowledges and agrees that it is Subtenant's
sole and exclusive responsibility to cause the Premises and Drawings to comply
with all applicable laws, including the Americans with Disabilities Act and
other ordinances, orders, roles, regulations and requirements of all
governmental authorities having jurisdiction thereof. Notwithstanding anything
to the contrary contained in the Sublease or herein, Sublessor's participation
in the preparation of the Space Plan, the Drawings and/or the Subtenant
Improvements shall not constitute any representation or warranty, express or
implied, that the (i) Drawings are in conformity with applicable codes,
regulations or roles or (ii) the Subtenant Improvements, if built in accordance
with the Drawings will be suitable for Subtenant's intended purposes. Subtenant
acknowledges and agrees that the Subtenant Improvements are intended for use by
Subtenant and the requirements for such improvements are not within the special
knowledge of Sublessor.
d. Subtenant shall repair or replace (or at Sublessor's election,
reimburse Sublessor for the cost of repairing or replacing) any portion of the
Building or Premises or Sublessor's property damage, lost or destroyed in
connection with the Work and shall indemnify, defend and hold Sublessor harmless
from and against any and all losses, costs, damages, expenses and liabilities,
including without limitation reasonable attorneys fees, incurred by Sublessor in
connection with the Work, including but not limited claims based on personal
injury or property damage, contract claims and/or lien claims.
e. There shall be no delay in the Commencement Date or the payment
of rent due to any delay in the Work.
4. Subtenant Alterations. Subtenant shall not make any alterations,
additions, or improvements to the Sublet Premises without the prior consent of
Sublessor. Sublessor's approval of the Drawings in accordance with Section 3
hereof shall be considered "prior consent" to the Work for proposes of this
section. All alterations, installations, removals and restoration shall be
performed in a good and workmanlike manner so as not to damage or alter the
primary structure or structural qualities of the Building and other improvements
situated on the Sublet Premises or of which the Sublet Premises are a part. All
alterations, installations, removals and restoration shall in addition be
subject to the requirements of Section 3 hereof (with the exception of the
payment of the Allowance, which is a one-time Allowance payable only in
connection .with the Work). All alterations, additions or improvements to the
Sublet Premises, including the Work, shall, at Sublessor's sole discretion,
either be removed by Subtenant prior to the end of the Term or earlier
termination thereof, or shall remain on the Premises at the end of the Term.
5. Use. Subtenant shall occupy and use the Premises only for research
and development and general office purposes and otherwise in strict compliance
with the allowable uses set forth in Section 5 of the Main Lease. Subtenant
shall not commit or suffer to be
3
<PAGE>
committed any annoyance waste, nuisance or any act or thing which is against
public policy, or which may disturb the quiet enjoyment of Sublessor or any
other tenant or occupancy of the Building. Subtenant agrees not to deface or
damage the Building in any manner. Subtenant shall not use the Premises for
any unlawful purposes.
6. Subordinate to Main Lease. This Sublease is and shall be subject and
subordinate to the Main Lease. A copy of the Main Lease (from which certain
economic terms have been excised) is attached hereto as Exhibit A and made a
part hereof. Sublessor agrees that it will not voluntarily enter into any
agreement with Overlandlord which would result in the termination of the Main
Lease prior to the Expiration Date or which would negatively affect the rights
or obligations of Subtenant under this Sublease. Sublessor shall notify
Subtenant of any involuntary change.
7. Compliance with Main Lease. Except as set forth in the immediately
succeeding sentence, the terms, covenants and conditions of the Main Lease (the
"Incorporated Provisions") are incorporated herein by reference. Sections
1,2,3,4,6, 7(B), 8, 9, 15, 16(E), 17(E), 22, 23, 44 and 52 and Exhibits B, C, D,
E, F, G and I of the Main Lease are specifically excluded from the Incorporated
Provisions. Except to the extent that the Incorporated Provisions are
inapplicable or are modified by the provisions of this Sublease, the
Incorporated Provisions binding or inuring to the benefit of the landlord
thereunder shall, in respect of this Sublease, bind or inure to the benefit of
Sublessor, and the Incorporated Provisions, binding or inuring to the benefit of
the tenant thereunder shall, in respect of this Sublease, bind or inure to the
benefit of Subtenant with the same force and effect as if such Incorporated
Provisions were completely set forth in this Sublease, and as if the words
"Landlord" and "Tenant" or words of similar import, wherever the same appear in
the Incorporated Provisions, were construed to mean, respectively, "Sublessor
and "Subtenant" in this Sublease, and as if the words "Premises," or words of
similar import, wherever the same appear in the Incorporated Provisions, were
construed to mean "Premises" in this Sublease, and as if the word "Lease," or
words of similar import, wherever the same appear in the Incorporated
Provisions, were construed to mean this "Sublease."
(a) The time limits contained in the Main Lease for the giving of
notices, making of demands or performing of any act, condition or covenant
on the part of the tenant thereunder, or for the exercise by the tenant
thereunder of any right, remedy or option, are changed for the purposes of
incorporation herein by reference by shortening the same in each instance
by 5 days, so that in each instance Subtenant shall have 5 days less time
to observe or perform hereunder than Sublessor has as the tenant under the,
Main Lease, except that:
(i) any such time limits which are 7 days or less shall instead
be shortened in each instance by 3 business days, and
(ii) any such time limits which are 3 days or less shall instead
be shortened in each instance so that such time limits shall expire 1
business day prior to the expiration of such time limits under the
Main lease.
(b) If any of the express provisions of this Sublease shall conflict
with any of the Incorporated Provisions, such conflict shall be resolved in
every instance in favor of the express provisions of this Sublease. If
Subtenant receives any notice or demand from Overlandlord under the Main
Lease, Subtenant shall deliver a copy thereof to Sublessor by overnight
courier the next business day or as soon thereafter as is reasonably
possible but in no event later than two business days after Subtenant's
receipt of such notice. If
4
<PAGE>
Sublessor receives any notice of default from Overlandlord under the Main
Lease, Sublessor shall deliver a copy thereof to Subtenant by overnight
courier the next business day or as soon thereafter as is reasonably
possible but in no event later than two business days after Sublessor's
receipt of such notice.
8. Performance by Sublessor. Sublessor shall not be required to furnish,
supply or install anything required under any article of the Main Lease.
Sublessor shall have no liability or responsibility whatsoever for
Overlandlord's failure or refusal to perform under the Incorporated Provisions.
Subtenant shall have the right to instruct Overlandlord with respect to the
performance by Overlandlord of Overlandlord's obligations as landlord under the
Main Lease. Upon Sublessor's receipt of a written notice from Subtenant that
Sublessor has failed to perform an obligation under the Incorporated Provisions,
(because of a failure of Overlandlord to perform its obligation under the Main
Lease) then Sublessor may, at its sole and exclusive option either (a) use its
reasonable efforts to cause Overlandlord to observe and perform the same,
provided, however, that Sublessor does not guarantee Overlandlord's compliance
with the Incorporated Provisions, or (b) direct Subtenant to pursue its claim
directly against Overlandlord which shall be done at Subtenant's sole cost and
expense. Subtenant shall not in any event have any rights in respect of the
Premises greater than Sublessor's rights under the Main Lease. Notwithstanding
any provision to the contrary contained herein, as to Incorporated Provisions,
Sublessor shall not be required to make any payment or perform any obligation,
and Sublessor shall have no liability to Subtenant for any matter whatsoever,
except for (i) Sublessor's obligation to pay the rent due under the Main Lease,
and (ii) Sublessor's obligation to use reasonable efforts, upon the written
request of Subtenant, to cause Overlandlord to observe and/or perform its
obligations under Main Lease (or, in the alternative, to direct Subtenant to
pursue its claim against Overlandlord). Sublessor shall not be responsible for
any failure or interruption, for any reason whatsoever, of the services or
facilities that may be appurtenant to or supplied at the Building, by
Overlandlord or otherwise, including, without limitation, heat, air
conditioning, water, elevator service and cleaning service, if any; and no
failure to furnish, or interruption of, any such services or facilities shall
give rise to any: (i) abatement, diminution or reduction of Subtenant's
obligations under this Sublease; (ii) constructive eviction, whether in whole or
in part; or (iii) liability on the part of Sublessor.
9. No Breach of Main Lease. Subtenant shall not do or permit to be done
any act or thing which may constitute a breach or violation of any term,
covenant or condition of the Main Lease.
10. No Privity of Estate. Nothing contained in this Sublease shall be
construed to create privity of estate or privity of contract between Subtenant
and Overlandlord.
11. Indemnity. Subtenant hereby does and shall indemnify, defend and hold
harmless Sublessor from and against all losses, costs, damages, expenses and
liabilities, including, without limitation, reasonable attorneys' fees, which
Sublessor may incur or pay by reason of: (i) Subtenant's use, occupancy or
management of the Premises; (ii) any accidents, damages or injuries to persons
or property occurring in, on or about the Premises; (iii) any breach or default
hereunder on Subtenants part; (iv) any work done by or on behalf of Subtenant in
or to the Premises, (v) the breach or inaccuracy of any representation or
warranty made by Subtenant hereunder, or (vi) any act, omission or negligence
occurring in, on or about the Premises on the part of Subtenant and/or its
officers, employees, agents, customers, invitees or any person claiming through
or under Subtenant.
5
<PAGE>
12. Rent.
(a) Subtenant shall pay to Sublessor base rent (the "Base Rent") as
follows:
Period Monthly Rent Per Square Foot Monthly Rent Annual Rent
------- ---------------------------- ------------ -------------
July 1, 1998 - June 30, 1999 $2.85 $148,727.25 $l,784,727.00
July 1, 1999 - June 30, 2000 $2.96 $154,467.60 $1,853,611.20
July 1, 2000 - June 30, 2001 $3.08 $160,729.80 $1,928,757.60
July 1, 2001 - June 30, 2002 $3.20 $166,992.00 $2,003,904.00
July 1, 2002 - June 30, 2003 $3.33 $173,776.05 $2,085,312.60
(b) Subtenant shall pay the Monthly Base Rent to Sublessor in advance
of the first day of each month during the Term at the offices of Sublessor
identified at the beginning of this Sublease or elsewhere as Sublessor
shall direct. Subtenant shall pay to Sublessor the first installment of
Monthly Base Rent upon Subtenant's execution of this Sublease. In addition
to the Monthly Base Rent, Subtenant shall also be responsible for and pay
the applicable material or service provider (including as the ease may be,
Sublessor Or Overlandlord) directly for any and all other amounts payable
with respect to providing: (i) gas, heat, air conditioning, electricity,
telephone, water, sewer, security services and janitorial services to the
Premises; and (ii) Subtenant's Proportionate Share (as defined in the
following sentence) of all costs with respect to the Building's common area
and systems, and the Building structure, including without limitation costs
of maintenance, repair and replacement of the Building structure common
area and systems, costs of utilities and security for the common areas and
a property management fee to the property manager selected by Sublessor or
Overlandlord; and (iii) Subtenant's Proportionate Share of any other
operating expenses to be paid by Sublessor under the Main Lease, including
without limitation, the Impositions and insurance costs. Subtenant's
Proportionate Share shall be Sixty-Five and one-half percent (65.5%). All
of the foregoing amounts shall be hereinafter collectively referred to as
the "Additional Charges".
(c) "Rent" (which term shall include the Base Rent and my Additional
Charges) shall be paid promptly when due, without notice or demand therefor
and without deduction, abatement, counterclaim or setoff of any amount for
any reason whatsoever. Base Rent and Additional Charges shall be paid to
Sublessor by good unendorsed check of Subtenant at the address of Sublessor
set forth at the beginning of this Sublease or to such other person and/or
at such other address as Sublessor may from time to time designate by
notice to Subtenant. No payment by Subtenant or receipt by Sublessor of any
lesser amount than the amount stipulated to be paid hereunder shall be
deemed other than on account of the earliest stipulated Base Rent or
Additional Charges due under this Sublease; nor shall any endorsement or
statement on any check or letter be deemed an accord and satisfaction, and
Sublessor may accept any check or payment without prejudice to Sublessor's
right to recover the balance due or to pursue any other remedy available to
Sublessor.
6
<PAGE>
(d) Upon the execution of (i) this Sublease by both Sublessor and
Subtenant and (ii) consent to this Sublease by Overlandlord as provided
herein, Subtenant shall be authorized to take possession of the Premises
seven (7) days prior to the Commencement Date for the limited purpose of
installing its equipment. Subtenant hereby agrees that if Subtenant takes
possession of the Premises prior to the Commencement Date, then from and
after the date Subtenant takes possession of the Premises (the "Possession
Date"), all of Subtenant's obligations and duties under this Sublease shall
be effective. Notwithstanding anything in this Sublease to the contrary,
with the exception of the Allowance, Subtenant shall pay all charges
incurred by Subtenant (including but not limited to fees, if any, charged
by Overlandlord) in connection with Subtenant's relocation to the Premises,
the installation of all equipment and utility services for the Premises
which axe required by Subtenant, including, but not limited to, telephones,
computers, and additional electric service.
13. Condition of Premises. Sublessor shall deliver the Premises to
Subtenant on the Commencement Date in "as is/where is" condition. Sublessor
shall have no obligations under this Sublease or otherwise to perform any work,
alterations, installations or to remove any asbestos or asbestos containing
material (collectively, "ACM"), if any, from the Premises or elsewhere.
Sublessor makes no representations or warranties whatsoever with respect to the
presence of ACM in the Premises. In making and executing this Sublease,
Subtenant has relied solely on such investigations, examinations and inspections
as Subtenant has chosen to make. Subtenant acknowledges that Sublessor has
afforded Subtenant the opportunity for full and complete investigations,
examinations, and inspections of the Premises.
14. Consents and Approvals. In any instance when Sublessor's consent or
approval is required under this Sublease, Sublessor's refusal to consent to or
approve any matter or thing shall be deemed reasonable and in good faith if such
consent or approval has not been obtained from Overlandlord; provided however,
Sublessor covenants to use reasonable efforts, at the sole cost and expense of
Subtenant (including, without limitation, reasonable attorneys' fees and
expenses), to obtain the consent or approval of Overlandlord and will indicate
to Overlandlord in those cases where its approval is conditioned upon
Overlandlord's approval that it has no objection thereto and agrees that if such
consent of Overlandlord shall not be required, Sublessor shall not unreasonably
withhold or delay its consent to such matter. In the event that Subtenant shall
seek the approval by or consent of Sublessor and Sublessor shall fail or refuse
to give such consent or approval, Subtenant shall not be entitled to any damages
from Sublessor for any withholding or delay of such approval or consent by
Sublessor.
15. Notice. All notices, consents, approvals, demands and requests which
are required or desired to be given by either party to the other hereunder shall
be in writing and shall be personally delivered, sent by telefax or by reputable
overnight courier delivery service or sent by United States registered or
certified mail and deposited in a United States post office, return receipt
requested and postage prepaid. Notices, consents, approvals, demands and
requests which are served upon Sublessor or Subtenant in the manner provided
herein shall be deemed to have been given or served for all purposes hereunder
on the day personally delivered or refused, the next business day after sending
by overnight courier as aforesaid, on the third business day after mailing as
aforesaid, or, if via telefax, on the date of transmission. All notices,
consents, approvals, demands, and requests given to Sublessor or Subtenant shall
be addressed to the address set forth at the beginning of this Sublease with
notices to Sublessor being addressed to the attention of Vice President - Real
Estate with a copy at the same time and in the same manner to Property
Administration, First Data Card Services Group, 11204 Chicago Circle, Omaha, NE
68154, Attention: Eileen Murdoch. Either party may from time to time change the
names and/or
7
<PAGE>
addresses to which notices, consents, approvals, demands and request shall be
addressed by a notice given in accordance with the provisions of this Paragraph.
16. Termination of Main Lease. If for any reason the term of the Main
Lease shall terminate prior to the Expiration Date, this Sublease shall
thereupon be terminated and Sublessor shall not be liable to Subtenant by reason
thereof unless both (a) Subtenant shall not then be in default hereunder, and
(b) said termination shall have been effected because of the breach or default
of Sublessor as tenant under the Main Lease.
17. Maintenance and Repairs. Subtenant shall, at Subtenant's sole cost
and expense, keep and maintain the Premises in good condition and repair,
including without limitation, all necessary maintenance and repairs to all
portions of the Premises and all exterior entrances, all glass, window
casements, show window moldings, all partitions, doors, doorjambs, door closers
and hardware fixtures exclusive of normal maintenance services. All damage or
injury to the Building and/or common areas in which the same are located, caused
by the negligence of Subtenant, its employees, agents or visitors, shall be
repaired by Subtenant at Subtenant's sole cost and expense. Subtenant shall
promptly replace any portion of the Premises which cannot be fully repaired,
regardless of whether the benefit of such replacement extends, beyond the Term.
It is the intention of Sublessor and Subtenant that, at all times during the
Term, Subtenant shall, at its cost, maintain the Premises in compliance with all
applicable laws and in the same condition as existed upon the Commencement Date
of the Sublease, reasonable wear and tear excepted. Notwithstanding the
foregoing, Sublessor hereby agrees to perform the repair obligations for the
Building as described in Section 7(A) of the Main Lease and Subtenant agrees to
reimburse Sublessor for its Proportionate Share of such repair costs after the
opportunity to review Sublessor's receipts for such repair costs. The cost of
any repair which is capital in nature shall be amortized on a straight line
basis over its useful life ("Useful Life") at an interest rate not to exceed ten
percent (10%) and Subtenant shall reimburse Sublessor the amount equal to
Subtenant's Proportionate Share of the annualized amortization during the Term
of this Sublease. The Useful Life of a capital item shall be determined using
the United States Internal Revenue Service standard depreciation schedule in
effect on the date that the applicable capital expenditure is made. Subtenant
shall also reimburse Subtenant's Proportionate Share of the annualized
amortization of any improvement or replacement which is capital in nature,
provided that the item is intended to result in a cast savings, then only to the
extent of saving actually realized. Subtenant shall not be required to reimburse
Sublessor for any changes, alterations or improvements to any portion of the
Building first required by any law or regulation prior to the Term Commencement
Date, to the extent not attributable to Subtenant's use and occupancy of the
Premises.
18. Assignment and Subletting. Subtenant shall not, by operation of law,
merger, consolidation or otherwise, assign, sell, mortgage, pledge or in any
manner transfer this Sublease or any interest therein, or sublet the Premises or
any part or parts thereof, or grant any concession or license or otherwise
permit occupancy of all or any part of the Premises by any person, except with
the prior written consent of Sublessor. Sublessor shall not unreasonably
withhold its consent to an assignment of this Sublease by Subtenant (which
assignment may nevertheless require the consent of Overlandlord), provided that
the assignee proposed by Subtenant shall demonstrate to the reasonable
satisfaction of Sublessor that such proposed assignee has a net worth and
financial capacity equal to or greater than the net worth and financial capacity
of Subtenant. Neither the consent of Sublessor to an assignment, subletting,
concession or license, nor the references in this Sublease to assignees,
subtenants, concessionaires or licensees, shall in any way be construed to
relieve Subtenant of the requirement of obtaining the consent of
8
<PAGE>
Sublessor to any further assignment, subletting, concession or license for all
or any part of the Premises. In the event Sublessor consents to any assignment
of this Sublease, the assignee shall execute and deliver to Sublessor an
agreement in form and substance satisfactory to Sublessor whereby the assignee
shall assume all of Subtenant's obligations under this Sublease from and after
the date of the assignment. Notwithstanding any assignment or subletting,
including, without limitation, any assignment or subletting permitted or
consented to, the original Subtenant named herein and any other person(s) who at
any time was or were Subtenant shall remain fully liable on this Sublease, and
if this Sublease shall be amended, modified, extended or renewed, the original
Subtenant named herein and any other person(s) who at any time was or were
Subtenant shall remain fully liable on this Sublease as so amended, modified,
extended or renewed. Any violation of any provision of this Sublease by any
assignee, subtenant or other occupant shall be deemed a violation by the
original Subtenant named herein, the then Subtenant and any other person(s) who
at any time was or were Subtenant, it being the intention and meaning that the
original Subtenant named herein, the then Subtenant and any other person(s) who
at any time was or were Subtenant shall all be liable to Sublessor for any and
all acts or omissions of any and all assignees, subtenants and other occupants
of the Premises claiming by, through or under Subtenant. If this Sublease shall
be assigned or if the Premises or any part thereof shall be sublet or occupied
by any person or persons other than the original Subtenant named herein,
Sublessor may collect rent from any such assignee and/or any subtenants or
occupants, and apply the net amounts collected to the Base Rent and Additional
Charges, but no such assignment, subletting, occupancy or collection shall be
deemed a waiver of any of the provisions of this Paragraph, or the acceptance of
the assignee, subtenant or occupant as Subtenant, or a release of any person
from the further performance by such person of the obligations of Subtenant
under this Sublease.
19. Insurance. Subtenant shall provide and maintain throughout the term
of this Sublease a policy or policies of comprehensive public liability
insurance in standard form naming Sublessor and Overlandlord as additional
insurance and otherwise complying with Section 17 of the Main Lease with limits
of not less than $2,000,000.00 combined single limit for both bodily injury or
death and for property damage, including water damage. A policy, binder or other
reasonable satisfactory evidence of such insurance shall be delivered to
Sublessor by Subtenant no less than ten (10) days before the Possession Date.
Subtenant shall procure and pay for renewals or replacements of such insurance
from time to time before the expiration thereof, and Subtenant shall deliver to
Sublessor such renewal or replacement policy or binder or other reasonably
satisfactory evidence of such insurance at least 30 days before the expiration
of any existing policy. All such policies shall be issued by companies licensed
to do business in the State of California and shall contain a provision whereby
the same cannot be cancelled or modified unless Sublessor is given at least 30
days' prior written notice by certified or registered mail of such cancellation
or modification.
20. Right to Cure Subtenant's Defaults and Damages. If Subtenant shall at
any time fail to make any payment or perform any other obligation of Subtenant
hereunder within the applicable cure period, if any, then Sublessor shall have
the right, but not the obligation, after five days' notice to Subtenant, or
without notice to Subtenant in the case of any emergency, and without waiving or
releasing Subtenant from any obligations of Subtenant hereunder, to make such
payment or perform such other obligation of Subtenant in such manner and to such
extent as Sublessor shall deem necessary, and in exercising any such right, to
pay any incidental costs and expenses, employ attorneys, and incur and pay
reasonable attorneys' fees. Subtenant shall pay to Sublessor upon demand all
sums so paid by Sublessor and all incidental costs and expenses of Sublessor in
connection therewith, together with interest thereon at the rate of 2% per
calendar month or any part thereof or the then maximum rate of interest which
may lawfully
9
<PAGE>
be collected from Subtenant, whichever shall be less, from the date of the
making of such expenditures.
21. Remedies of Sublessor.
(a) "Default" shall mean a default by Subtenant under any provision
of this Sublease which default has not been cured within any applicable
grace or cure period.
(b) If a Default occurs, Sublessor shall have, in addition to all its
rights and remedies contained in the Incorporated Provisions pursuant to
Section 4 hereof, the following rights and remedies; all of Sublessor's
rights and remedies under this Sublease are distinct, separate and
cumulative, and none will exclude any other right or remedy allowed by law:
(i) Sublessor may, with or without notice of such election and
with or without entry or other action by Sublessor, immediately
terminate this Sublease, in Which event the Term of this Sublease
shall end and all right, rifle, and interest of Subtenant hereunder
shall expire; or
(ii) Sublessor may enforce the provisions of this Sublease and
may enforce and protect the rights of the Sublessor hereunder by a
suit or suits in equity or at law for the specific performance of any
covenant or agreement herein or for the enforcement of any other
appropriate legal or equitable remedy, including the recovery of all
moneys due or to become due under any of the provisions of this
Sublease.
(c) If Sublessor elects to terminate Subtenants right to possession
only without terminating this Sublease, Sublessor, at Sublessor's option,
may enter into the Premises, remove Subtenant's signs and other evidences
of tenancy, and take and hold possession thereof without such entry and
possession terminating this Sublease or releasing Subtenant, in whole or in
part, from Subtenant's obligation to pay Rent under this Sublease for the
full Term, and in the case Sublessor elects to terminate the Sublease or to
terminate possession only, Subtenant will immediately pay to Sublessor, if
Sublessor so elects, a sum equal to the then present value (as defined in
the following sentence) of the entire amount of the Rent specified in
Section 9 of this Sublease for the remainder of the Term, plus any other
sums then due under this Sublease, less the fair rental value of the
Premises for such period. In calculating this sum, present value shall be
computed on the basis of a discount rate of six percent per annum. In the
alternative, upon and after entry into possession without termination of
the Sublease, Sublessor will use its best efforts to relet all or any part
of the Premises for Subtenant's account for such rent and for such time and
upon such terms as Sublessor in Sublessor's sole discretion may determine.
Sublessor will not be required to observe any instruction given by
Subtenant about such reletting. Subtenant will, upon demand, pay the cost
of Sublessor's expenses of the reletting. If the consideration collected by
Sublessor upon any such reletting for Subtenant's account is not sufficient
to pay monthly the full amount of the Rent due under this Sublease,
together with the costs of Sublessor's expenses, Subtenant will pay to
Sublessor the amount of each monthly deficiency upon demand.
(d) Subtenant will pay upon demand all of Sublessor's costs,
charges, and expenses, including reasonable attorneys' fees, and fees and
expenses of agents and
10
<PAGE>
others retained by sublessor in any litigation, negotiation or transaction
in which Sublessor seeks to enforce the terms or provisions of this
sublease.
22. Brokerage. Sublessor and Subtenant each represents to the other that
except for the Staubach Company ("Sublessor's Broker") and Colliers Parrish
International, Inc ("Subtenant's Broker")(collectively, the "Sublease Brokers"),
no broker or other person had any part, or was instrumental in any way, in
bringing about this Sublease. Sublessor agrees to pay the Sublessor's Broker for
services rendered in connection with this Sublease pursuant to the Agreement
(the "Broker Agreement") between Sublessor and the Sublessor's Broker. By its
execution hereof Sublessor's Broker agrees to pay Subtenant's Broker one-half of
Sublessor's Broker's commission. Sublessor and Subtenant each agree to
indemnify, defend and hold harmless the other from and against, any claims made
by any broker or any person, other than the Sublease Brokers, for a brokerage
commission, finder's fee, or similar compensation, by reason of or in connection
with this Sublease, and any loss, liability, damage, cost and expense
(including, without limitation, reasonable attorneys' fees) in connection with
such claims if such broker or other person had, or claimed to have, dealings
with such party in bringing about this Sublease. The provisions of this
Paragraph 22 shall survive the expiration or termination of this Sublease.
23. Waiver of Jury Trial and Right to Counterclaim. Subtenant hereby
waives all right to trial by jury in any summary or other action, proceeding or
counterclaim arising out of or in any way connected with this Sublease. With the
exception of any compulsory counterclaims, Subtenant also hereby waives all
right to assert or interpose a counterclaim in any summary proceeding or other
action or proceeding to recover or obtain possession of the Premises unless
legally required to do so to preserve the claim.
24. No Waiver. The failure of Sublessor to insist in any one or more
cases upon the strict performance or observance of any obligation of Subtenant
hereunder or to exercise any right or option contained herein shall not be
construed as a waiver or relinquishment for the future of any such obligation of
Subtenant or any right or option of Sublessor. Sublessor's receipt and
acceptance of Base Rent or Additional Charges, or Sublessor's acceptance of
performance of any other obligation by Subtenant, with knowledge of Subtenant's
breach of any provision of this Sublease, shall not be deemed a waiver of such
breach. No waiver by Sublessor of any term, covenant or condition of this
Sublease shall be deemed to have been made unless expressed in writing and
signed by Sublessor.
25. Complete Agreement. There are no representations, agreements,
arrangements or understandings, oral or written, between the parties relating to
the subject matter of this Sublease which are not fully expressed in this
Sublease. This Sublease cannot be changed or terminated orally or in any other
manner other than by a written agreement executed by both parties.
26. Successors and Assigns. The provisions of this Sublease, except as
herein otherwise specifically provided, shall extend to, bind and inure to the
benefit of the parties hereto and their respective personal representatives,
heirs, successors and permitted assigns. In the event of any assignment or
transfer of the leasehold estate under the Main Lease, the transferor or
assignor, as the case may be, shall be and hereby is entirely relieved and freed
of all obligations under this Sublease arising after the date of any such
assignment or transfer, except that Sublessor shall not be relieved and freed of
its payment obligations to Overlandlord under the Main Lease which payment
obligations are greater than the payment obligations of Subtenant to Sublessor
hereunder unless Overlandlord and Sublessor otherwise agree.
11
<PAGE>
27. Interpretation. Irrespective of the place of execution or performance,
this Sublease shall be governed by and construed in accordance with the laws of
the state where the Premises is located. If any provision of this Sublease or
the application thereof to any person or circumstance shall, for any reason and
to any extent, be invalid or unenforceable, the remainder of this Sublease and
the application of that provision to other persons or circumstances shall not be
affected but rather shall be enforced to the extent permitted by law. The table
of contents, captions, headings and titles, if any, in this Sublease are solely
for convenience of reference and shall not affect its interpretation. This
Sublease shall be construed without regard to any presumption or other rule
requiring construction against the party causing this Sublease to be drafted.
Each covenant, agreement, obligation or other provision of this Sublease shall
be deemed and construed as a separate and independent covenant of the party
bound by, undertaking or making same, not dependent on any other provision of
this Sublease unless otherwise expressly provided. All pronouns and any
variations thereof shall be deemed to refer to the masculine, feminine or
neuter, singular or plural, as the identity of the parties may require. The word
"person" as used in this Sublease shall mean a natural person or persons, a
partnership, a corporation or any other form of business or legal association
or. entity. This Sublease may be executed in counterparts or with counterpart
signature pages.
28. Consent of Landlord Under Main Lease. This Sublease shall not be
operative or effective for any purpose whatsoever unless and until Overlandlord
shall have given its written consent as provided hereto and any conditions
precedent with respect to such consent have been satisfied or waived. Sublessor
shall have no obligation to satisfy any such conditions precedent provided,
however, that Subtenant may, but shall not be obligated to, satisfy any such
conditions precedent and Sublessor shall reasonably cooperate with Subtenant (at
no cost or expense to Sublessor) in this regard.
29. Holding Over. Subtenant shall pay Sublessor a sum for each day that
Subtenant retains possession of the Premises or any part thereof after
termination of this Sublease, by lapse of time or otherwise, equal to two (2)
times the Rent payable hereunder, and Subtenant shall also pay damages
consequential as well as direct, sustained by Sublessor by reason of such
retention. Nothing in this Section contained, however, shall be construed or
operate as a waiver of Sublessor's right of reentry or any other right of
Sublessor under this Sublease or of Overlandlord under the Main Lease.
30. Security Deposit. Subtenant agrees to deposit with Sublessor, upon
the execution of this Sublease, $297,454.50 in cash (the "Cash Security Deposit"
and $594,909.00 in the form of an irrevocable letter of credit issued by a bank
acceptable to Sublessor in form and substance satisfactory to Sublessor (the
"Letter of Credit") (the "Cash Security Deposit" and the "Letter of Credit" are
sometimes hereinafter collectively referred to as the "Security Deposit"), which
Security Deposit is security for the full and faithful performance by Subtenant
of every term, provision, covenant, and condition of this Sublease. The Cash
Security Deposit will be held by Sublessor, provided however, that Sublessor
will have no obligation to segregate the amount from Sublessor's other funds.
Upon the occurrence of a Default by Subtenant in respect to any of the terms,
provisions, covenants, or conditions of this Sublease, including, but not
limited to, payment of Rent, Sublessor may use, apply, or retain the whole or
any part of the Cash Security Deposit so deposited for the payment of any such
Rent in default, or for any other sum which Sublessor may expend or be required
to expend by reason of Subtenant's Default, including without limitation, any
damage or deficiency in the reletting of the Premises, whether such damage or
deficiency accrued before or after any reentry by Sublessor. If any of the Cash
Security Deposit is so used, Subtenant, on written demand by Sublessor, will
promptly pay to Sublessor such additional sum as may be necessary to restore the
deposit to the original amount
12
<PAGE>
set forth in this Section. In addition, upon the occurrence of a default by
Subtenant in respect to any of the terms, provisions, covenants or conditions of
this Sublease, including, but not limited to, payment of Rent, Sublessor may
also draw on the Letter of Credit and apply such amount to the payment of any
sum in default or any other sum which Sublessor may require or deem necessary to
spend or incur by reason of Subtenant's default. In such event, Subtenant shall,
upon demand, increase the Letter of Credit by the amount so applied to replenish
the Letter of Credit. Notwithstanding the foregoing, in the event of a
nonmonetary Default by Subtenant, Sublessor shall give Subtenant 48 hours
advance written notice prior to using any portion of the Security Deposit. The
Letter of Credit shall be payable to Sublessor or its successors and assigns and
have an expiration date no earlier than the one-year anniversary of the
Commencement Date and be automatically renewable for consecutive one year
periods through and including the Expiration Date. If not renewed at least
thirty (30) days prior to the end of each such one-year period, Sublessor shall
be permitted to draw the full amount of the Letter of Credit. The Letter of
Credit shall expressly provide, among other things, that Sublessor may draw
under it by presentation of a sight draft and a written certification by
Sublessor that Sublessor is then entitled to draw the amount of the draft.
Sublessor's right to draw upon the Cash Security Deposit and/or the Letter of
Credit shall be cumulative, and Sublessor shall be entitled to draw upon either
or both, and shall not be required to deplete either portion of the Security
Deposit before proceeding to draw on the other portion of the Security Deposit.
Provided Subtenant is not in material default of this Sublease, the principal
sum of the Letter of Credit shall be reduced by fifty (50%) on the first day
of the thirteenth (13th ) month of the Sublease Term. If Subtenant fully and
faithfully complies with all of the terms, provisions covenants, and conditions
of this Sublease, the Cash Security Deposit, or any balance thereof will be
returned to Subtenant after the last to occur of the following:
(a) the time fixed as the expiration of the Term of this Sublease;
(b) the surrender of the Premises by Subtenant to Sublessor in
accordance with this Sublease;
(c) the receipt of Sublessor of all sums due pursuant to the
Sublease. Except as otherwise required by law, Subtenant will not be
entitled to any interest on such Cash Security Deposit.
31. Counterparts. This Sublease may be executed in two or more
counterparts, each of which shall be deemed an original but all of which
together shall constitute but one and the same instrument.
32. No Offer. The submission of this Sublease shall not be deemed to be
an offer, an acceptance, or a reservation of the Premises; and Sublessor shall
not be bound hereby until Sublessor has delivered to Subtenant a fully executed
copy of this Sublease, signed by both of the parties on the last page of this
Sublease in the spaces herein provided. Until such delivery, Sublessor reserves
the right to exhibit and lease the Premises to other prospective tenants.
33. Hazardous Materials. Subtenant shall comply with any and all EnvLaws.
Subtenant shall not (a) cause, permit or allow the presence of any Hazardous
Substance on the Premises, or (b) conduct or authorize the use, generation,
release, transportation, storage, treatment or disposal of Hazardous Substances
at the Premises.
34. Signage. Subject to the prior consent of Sublessor and Overlandlord
and provided all such signage complies with all applicable governmental laws,
ordinances, rules or
13
<PAGE>
regulations, does not cause any structural damage or other damage to the
Building, does not violate any existing restrictions affecting the Building, and
is compatible with the architecture of the Building and the landscaped are
adjacent thereto, Subtenant shall have the right to install, as Subtenant's sole
cost and expense: (a) door signage at the entrance to the Premises; and (b) a
monument sign and directional signage. Subtenant shall remove all signage from
the Premises at the end of the Term.
35. Parking. Subtenant shall have the non-exclusive right to the parking
spaces allocated to the Premises at a ratio of approximately 4 parking space to
1,000 rentable square feet of Premises at no additional charge. Subtenant, its
agents, employees, invitees and contractors shall comply with Building rules and
regulations applicable to use of the parking areas.
37. Rules and Regulations; Common Areas. Subtenant shall comply with all
reasonable rules and regulations and all subsequent amendments and modifications
established by Sublessor or Overlandlord with respect to the Building and common
areas thereof; and shall cause its employees, customers, contractors, agents and
invitees to so comply. Without liability to Subtenant and without effecting an
eviction or disturbance of Subtenant's use or possession or giving rise to any
claim for set-offs or abatement of Rent, and without imposing any obligation on
Sublessor or Overlandlord to undertake any of the same, Sublessor (or
Overlandlord, as the case may be) shall have the right to: (a) make changes,
repairs, additions or alterations to the common areas of the Building, including
without limitation changes in the location, size, shape-and number of driveways,
entrances, parking areas, loading areas, ingress/egress, direction of traffic,
landscaped areas and walkways and changes in the arrangement or location of
entrances or passageways, doors and doorways, corridors, stairs, toilets or
other public parts of the Building; (b) close any of the common areas for
maintenance purposes, including entrances, doors, corridors or other facilities;
(c) perform any acts related to the safety, protection, preservation, reletting
or improvement of the Building; (d) change the name or street address of the
Building or suite number of the Premises; (e) to require all persons entering or
leaving the Building to identify themselves to security personnel by
registration or otherwise; and (f) to close the Building after-hours and on
week-ends.
14
<PAGE>
IN WITNESS WHEREOF, Sublessor and Subtenant have executed this Sublease as
of the day and year first above written.
SUBLESSOR: FIRST DATA MERCHANT SERVICES CORPORATION, a
Florida corporation
By: /s/ David Schlapbach
---------------------------------------
Name: David Schlapbach
-------------------------------------
Title: Assistant Secretary
------------------------------------
SUBTENANT: SOFTWARE.NET CORPORATION, a California
corporation
By: /s/ Michael J. Praisner
---------------------------------------
Name: Michael J. Praisner
-------------------------------------
Title: CFO
-----------------------------------
The undersigned Sublease Brokers join in this Lease for purposes of agreeing to
be bound by the provisions of Paragraph 22 hereof.
THE STABAUCH COMPANY COLLIER'S PARISH INTERNATIONAL, INC.
By: /s/ Anthony Lautmann By: /s/ Robert Shepherd
--------------------------------- ---------------------------------
Name: Anthony Lautmann Name: Robert Shepherd
------------------------------- -------------------------------
Title: President, NW Corp Svcs Title: Senior Vice President
------------------------------ ------------------------------
15
<PAGE>
ACKNOWLEDGED AND CONSENTED TO:
Sunnyvale Partners Limited Partnership, landlord under the Main Lease,
hereby consents to the sublease of the Premises described in the foregoing
Sublease and confirms that the consent given hereby satisfies the requirements
for landlord's consent of the subletting of the Premises set forth in the Main
Lease.
SUNNYVALE PARTNERS LIMITED PARTNERSHIP
By: /s/ James G. Martell
-----------------------------------
Name: James G. Martell
---------------------------------
Title: President Ridge Sunnyvale Inc.
--------------------------------
President
16
<PAGE>
EXHIBIT A
THE MAIN LEASE
--------------
17